Changes to Plans. After the plans are deemed final, the plans shall not be subject to further change except as provided under this Paragraph. If either Landlord or Tenant desires any change to the plans after they are deemed final, it shall submit to the other for approval (which approval shall not be unreasonably withheld) a proposed change order, in writing, setting forth the change. Thereupon the other party shall either approve the proposed change order or notify the party submitting the proposed change order of its reason for withholding such approval, within two (2) business days after receipt of the proposed change order for approval. Without limiting the reasons for which approval of any proposed change order may be reasonably withheld, approval shall be deemed to have been reasonably withheld if the proposed change (1) would result in additional construction maintenance repair or replacement costs which could not be fully borne by the party proposing the change, (2) would result in a violation of any applicable law, regulation, ordinance or code, or (3) in the case of a change proposed by Landlord would materially reduce the usable area of the Building or would materially adversely affect the aesthetics of the Leased Premises or the usability thereof for the conduct of Tenant’s business. Upon approval of any proposed change order pursuant to this Paragraph, Landlord shall cause the plans and construction contracts to be modified or amended as necessary to reflect such change order.
Changes to Plans. (a) Project Co shall submit to Contracting Authority, in accordance with Schedule 10 – Review Procedure, any changes to any of the Quality Plans required to comply with Section 15.1, and shall amend such Quality Plans as required pursuant to Schedule 10 – Review Procedure.
Changes to Plans. Tenant shall have the right to request that ---------------- Landlord make changes to the Plans (a "Change Order"), which requests shall be in a writing delivered to Landlord and shall not be unreasonably denied; provided, however, that the incremental increase or decrease of the overall costs of constructing the Improvements directly attributable to a Change Order shall be reflected increasing or decreasing the rent payable under this Lease. (Amount of Cost Increase or Cost Decrease) x (1.09) x *(.0954) = -------------------------------------------------------------- (12) (Amount to be Added to or Subtracted from Tenant's Monthly Rent) In the event a Change Order results in the total square footage of the Building as set forth in subparagraph 4(a) hereof, being increased or decreased, such square footage and Rent payable hereunder shall be proportionately adjusted. Anything herein to the contrary notwithstanding, in the event the additional work contemplated by a Change Order will result in a delay in completing a Key Task or Benchmark Task, Landlord, within ten (10) days after receipt of the Change Order, will notify Tenant of such in a writing specifying the Key Task or Benchmark Task which will be delayed and the anticipated length of the delay. Tenant shall have five (5) days following receipt of Landlord's notification in which to either, at Tenant's option, (i) rescind in writing the Change Order, (ii) dispute in writing anticipated length of delay set forth in Landlord's notification, in which event Landlord and Tenant shall have five (5) additional days in which to arrive at a mutually agreeable length of anticipated delay and, failing such mutual agreement, the anticipated length of delay shall be determined pursuant to the arbitration provisions of Paragraph 29 herein, (provided however, that construction under the Change Order shall commence immediately and shall not await determination of the length of delay under this subparagraph 2(h), or (iii) approve the length of the anticipated delay. In the event Tenant does not notify Landlord of Tenant's election with five (5) days after receipt of Landlord's notification of anticipated delay, Tenant shall be deemed to have approved the anticipate length of delay * This rate is subject to equitable adjustment in the event the Change Order results in any special additions to the Parcel 1 Improvements not contemplated by the Plans and not practically capable of amortization as provided for herein. Any d...
Changes to Plans. (a) In the event of any Change Order or in the event that Lessor determines that any of Lessee’s Plans have not been prepared in accordance with the requirements of this Work Agreement, Lessee shall be solely responsible for all costs and expenses and for all delays in reoccupancy by Lessee resulting therefrom including, without limitation, costs or expenses relating to (i) any additional architectural or engineering services and related design expenses; (ii) any reasonable architectural or engineering costs incurred by Lessor in connection with its review of such requested change; (iii) any changes to materials in process of fabrication; (iv) cancellation or modification of supply or fabricating contracts; (v) removal or alteration of work or plans completed or in process; or (vi) delay claims made by Contractor.
Changes to Plans. (a) Project Co shall submit to the College, in accordance with Schedule 10 – Review Procedure, any changes to any of the Quality Plans required to comply with Section 15.1, and shall amend such Quality Plans as required pursuant to Schedule 10 – Review Procedure.
Changes to Plans. (a) Project Co shall submit to HMQ, in accordance with Schedule 10 - Review Procedure, any changes to any of the Quality Plans required to comply with Section 13.1, and shall amend such Quality Plans as required pursuant to Schedule 10 - Review Procedure.
Changes to Plans. (a) Project Co shall submit to IO, in accordance with Schedule 10 - Review Procedure, any changes to any of the Quality Plans required to comply with Section 13.1, and shall amend such Quality Plans as required pursuant to Schedule 10 - Review Procedure.
Changes to Plans. Changes to plans are at the sole discretion of the Vendor, and may not be permitted. Verbal representations of the Sales Agent do not form part of this Agreement. If changes are accepted and allowed by the Vendor, such changes may be subject to additional cost which will be added to the Purchase Price. 2 Furthermore, any request for change will likely result in delay, which, in turn, will require the Purchasers to agree to change the Closing Date. The Purchasers understand that the Purchasers will be required to waive any entitlement to Tarion compensation for any delay so caused, failing which the Vendor will not agree to the requested change.
Changes to Plans. The Employer may institute a plan which is equal or superior to a plan referred to in this Article other than Long Term Disability.
Changes to Plans. (a) Project Co shall submit to HHS, in accordance with Schedule 10 - Review Procedure, any changes to any of the Quality Plans required to comply with Section 13.1, and shall amend such Quality Plans as required pursuant to Schedule 10 - Review Procedure.
