Software Maintenance Subrecipient shall apply security patches and upgrades in a timely manner and keep virus software up-to-date on all systems on which State data may be stored or accessed.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.
Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Support and Maintenance Where Licensee purchases support and/or maintenance services, Licensee’s initial support and/or maintenance term will begin upon delivery to Licensee of the Licensed Software and continue for one (1) year thereafter (or the length of the term if less than a year for any subscription/term license) unless otherwise specified in the applicable annual support and/or maintenance agreement, Product Order, or other written agreement executed between Licensor and Licensee. Where Licensee purchases support and/or maintenance for any Licensed Software, Licensee hereby agrees that it shall purchase such support and/or maintenance services for all of Licensee’s licensed units of such Licensed Software product. Support and/or maintenance services provided by Licensor will be subject to Licensor’s then current applicable standard annual support and/or maintenance agreement unless otherwise agreed by the parties in writing.
Service Level Agreement 6.1 NCR Voyix will use commercially reasonable efforts to make the Service available to you at or above the Availability Rate set forth at xxxxx://xxx.xxx.xxx/support/aloha-sla. If NCR Voyix does not meet the Availability Rate, you are entitled to request a service-level credit subject to the terms of this Agreement. This credit is calculated as a percentage of the monthly recurring bill (or monthly pro rata share of billing, if billing does not occur monthly) for the Service for the month in which the Availability Rate was not met. The Availability Rate is determined by: (a) dividing the total number of valid outage minutes in a calendar month by the total number of minutes in that month; (b) subtracting that quotient from 1.00; (c) multiplying that difference by 100; and (d) rounding that result to two decimal places in accordance with standard rounding conventions. The number of outage minutes per day for a given service is determined by the lesser of the number of outage minutes.
6.2 Unavailability due to other conditions or caused by factors outside of NCR Voyix’s reasonable control will not be included in the calculation of the Availability Rate. Further, the following are expressly excluded from the calculation of the Availability Rate: (a) service unavailability affecting services or application program interfaces that are not used by you; (b) cases where fail-over to another data center is available but not utilized; (c) transient time-outs, required re-tries, or slower-than-normal response caused by factors outside of NCR Voyix’s reasonable control; (d) Scheduled Downtime, including maintenance and upgrades; (e) force majeure; (f) transmission or communications outages outside the NCR Voyix- controlled environment; (g) store-level down-time caused by factors outside of NCR Voyix’s reasonable control; (h) outages attributable to services, hardware, or software not provided by NCR Voyix, including, but not limited to, issues resulting from inadequate bandwidth or related to third-party software or services;
(i) use of the Service in a manner inconsistent with the documentation for the application program interface or the NCR Voyix Product; (j) your Point of Sale (“POS”) failure or the failure to properly maintain the POS environment, including updating the POS firmware or version of the software running on the POS as recommended by either NCR Voyix, a third-party POS reseller or servicer; and (k) issues related to third party domain name system (“DNS”) errors or failures.
6.3 To obtain a service-level credit, you must submit a claim by contacting NCR Voyix through the website at xxxxx://xxx.xxx.xxx/support/aloha-sla Your failure to provide the claim and other information will disqualify you from receiving a credit. NCR Voyix must receive claims within 60 days from the last day of the impacted month. After that date, claims are considered waived and will be refused. You must be in compliance with the Agreement in order to be eligible for a service-level credit. You may not unilaterally offset for any performance or availability issues any amount owed to NCR Voyix. If multiple Services experience an outage in a given month, the total credit for that month will be the highest credit allowed for any single Service which failed; there is no stacking of credits.
6.4 The remedies set forth in the Section are your sole and exclusive remedies for performance or availability issues affecting the Services, including any failure by NCR Voyix to achieve the Availability Rate.
Aircraft Maintenance Operator shall, at its own expense, cause the Aircraft to be inspected, maintained, serviced, repaired, overhauled, and tested in accordance with FAR Part 91 so that the Aircraft will remain in good operating condition and in a condition consistent with its airworthiness certification and shall take such requirements into account in scheduling the Aircraft hereunder, including but not limited compliance with applicable airworthiness directives and service bulletins. Performance of maintenance, preventive maintenance or inspection shall not be delayed or postponed for the purpose of scheduling the Aircraft unless such maintenance or inspection can safely be conducted at a later time in compliance with applicable laws, regulations and requirements, and such delay or postponement is consistent with the sound discretion of the pilot-in-command. In the event that any non-standard maintenance is required during the term and will interfere with User’s requested or scheduled flights, Operator, or Operator’s pilot-in-command, shall notify User of the maintenance required, the effect on the ability to comply with User’s requested or scheduled flights and the manner in which the parties will proceed with the performance of such maintenance and conduct of such flight(s). In no event shall Operator be liable to User or any other person for loss, injury or damage occasioned by the delay or failure to furnish the Aircraft under this Agreement, whether or not maintenance-related.
Software License Agreement 1) Customers acquiring software licenses under the Contract shall hold, use and operate such software subject to compliance with the Software License Agreement set forth in Appendix D of this Contract. No changes to the Software License Agreement terms and conditions may be made unless previously agreed to between Vendor and DIR. Customers may not add, delete or alter any of the language in Appendix D; provided however, that a Customer and Vendor may agree to additional terms and conditions that do not diminish a term or condition in the Software License Agreement, or in any manner lessen the rights or protections of Customer or the responsibilities or liabilities of Vendor. Order Fulfiller shall make the Software License Agreement terms and conditions available to all Customers at all times.
2) Compliance with the Software License Agreement is the responsibility of the Customer. DIR shall not be responsible for any Customer’s compliance with the Software License Agreement. If DIR purchases software licenses for its own use under this Contract, it shall be responsible for its compliance with the Software License Agreement terms and conditions.
Maintenance Agreement The parties will abide by the terms of the Maintenance Agreement including the capacity to dispute the classification in accordance with the Maintenance Agreement (Information Appendix C).
