Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Construction Phase Part 1 –
PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement.
6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services.
6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards.
6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal.
6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows:
6.4.1 A pre-established lump sum amount; or
6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or
6.4.3 As otherwise agreed in advance and in writing.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Construction Phase Services 3.1.1 – Basic Construction Services
Access to Premises Section 14.1 Tenant shall permit Landlord, Landlord’s agents and public utilities servicing the Building to erect, use and maintain concealed ducts, pipes and conduits in and through the Premises, provided that Landlord will not thereby reduce the rentable area of the Premises, other than to a de minimis extent. Landlord or Landlord’s agents shall have the right to enter the Premises at all reasonable times upon reasonable prior notice (except no such prior notice shall be required in case of emergency), which notice may be oral, to examine the same, to show them to prospective purchasers, Mortgagees, Lessors or lessees of the Building and their respective agents and representatives or prospective tenants of the Premises, and to make such repairs, alterations, improvements or additions (a) as Landlord may deem necessary or desirable to the Premises or to any other portion of the Building, or (b) which Landlord may elect to perform following Tenant’s failure to make repairs or perform any work which Tenant is obligated to make or perform under this Lease, or (c) for the purpose of complying with Legal Requirements, and Landlord shall be allowed to take all material into and upon the Premises that may be required therefor without the same constituting an eviction or constructive eviction of Tenant in whole or in part and Fixed Rent and Additional Rent will not be abated while said repairs, alterations, improvements or additions are being made, by reason of loss or interruption of business of Tenant, or otherwise.
Section 14.2 If Tenant shall not be present when for any reason entry into the Premises shall be necessary or permissible, Landlord or Landlord’s agents may enter the same without rendering Landlord or such agents liable therefor (if during such entry Landlord or Landlord’s agents shall accord reasonable care to Tenant’s property), and without in any manner affecting this Lease. Nothing herein contained, however, shall be deemed or construed to impose upon Landlord any obligation, responsibility or liability whatsoever for the care, supervision or repair of the Building or any part thereof, other than as herein provided.
Section 14.3 Landlord shall have the right from time to time to alter the Building and, without the same constituting an actual or constructive eviction and without incurring any liability to Tenant therefor, to change the arrangement or location of entrances or passageways, doors and doorways, and corridors, elevators, stairs, toilets, or other public parts of the Building and to change the name, number or designation by which the Building is commonly known; provided, however, that Landlord shall not make any permanent alterations which will deny or substantially interfere with Tenant’s access to the Premises from the public areas of the Building. All parts (except surfaces facing the interior of the Premises) of all walls, windows and doors bounding the Premises (including exterior Building walls, exterior core corridor walls, exterior doors and entrances other than doors and entrances solely servicing the Premises), all balconies, terraces and roofs adjacent to the Premises, all space in or adjacent to the Premises used for shafts, stacks, stairways, chutes, pipes, conduits, ducts, fan rooms, heating, air cooling, plumbing and other mechanical facilities, service closets and other Building facilities are not part of the Premises, and Landlord shall have the use thereof, as well as access thereto through the Premises for the purposes of operation, maintenance, alteration and repair. Landlord shall use reasonable efforts to minimize interference with Tenant’s access to and use and occupancy of the Premises in connection with any actions by Landlord permitted under this Section 14.3; provided, however, that Landlord shall have no obligation to employ contractors or labor at overtime or other premium pay rates or to incur any other overtime costs or additional expenses whatsoever.
