CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.
Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Termination Fee; Expenses (a) In recognition of the efforts, expenses and other opportunities foregone by CenterState while structuring and pursuing the Merger, Charter shall pay to CenterState a termination fee equal to $14,485,624 (“Termination Fee”), by wire transfer of immediately available funds to an account specified by CenterState in the event of any of the following: (i) in the event CenterState terminates this Agreement pursuant to Section 7.01(g) or Charter terminates this Agreement pursuant to Section 7.01(h), Charter shall pay CenterState the Termination Fee within one (1) Business Day after receipt of CenterState’s notification of such termination; and (ii) in the event that after the date of this Agreement and prior to the termination of this Agreement, an Acquisition Proposal shall have been made known to senior management of Charter or has been made directly to its stockholders generally or any Person shall have publicly announced (and not withdrawn) an Acquisition Proposal with respect to Charter and (A) thereafter this Agreement is terminated (x) by either CenterState or Charter pursuant to Section 7.01(c) because the Requisite Charter Stockholder Approval shall not have been obtained or (y) by CenterState pursuant to Section 7.01(d) or Section 7.01(e) and (B) prior to the date that is twelve (12) months after the date of such termination, Charter enters into any agreement or consummates an Acquisition Transaction with respect to an Acquisition Proposal (whether or not the same Acquisition Proposal as that referred to above), then Charter shall, on the earlier of the date it enters into such agreement and the date of consummation of such Acquisition Transaction, pay CenterState the Termination Fee, provided, that for purposes of this Section 7.02(a)(ii), all references in the definition of Acquisition Transaction to “20%” shall instead refer to “50%.”
(b) If CenterState or Charter terminates this Agreement pursuant to Section 7.01(b) and the denial of the applicable Regulatory Approval by the applicable Governmental Authority is caused solely by CenterState and its Subsidiaries, CenterState shall, on the date of termination, pay to Charter the sum of $2,000,000 (the “Reverse Termination Fee”). The Reverse Termination Fee shall be paid to Charter in same-day funds.
(c) Charter and CenterState each agree that the agreements contained in this Section 7.02 are an integral part of the transactions contemplated by this Agreement, and that, without these agreements, CenterState would not enter into this Agreement; accordingly, if Charter fails promptly to pay any amounts due under this Section 7.02, Charter shall pay interest on such amounts from the date payment of such amounts were due to the date of actual payment at the rate of interest equal to the sum of (i) the rate of interest published from time to time in The Wall Street Journal, Eastern Edition (or any successor publication thereto), designated therein as the prime rate on the date such payment was due, plus (ii) 200 basis points, together with the costs and expenses of CenterState (including reasonable legal fees and expenses) in connection with such suit.
(d) Notwithstanding anything to the contrary set forth in this Agreement, the Parties agree that if a Party pays or causes to be paid to the other Party the Termination Fee in accordance with Section 7.02(a) or the Reverse Termination fee in accordance Section 7.02(b), as applicable, the Party paying such Termination Fee or Reverse Termination (or any successor in interest thereof) will not have any further obligations or liabilities to the other Party with respect to this Agreement or the transactions contemplated by this Agreement.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Termination Fee (i) The Company shall pay to Parent the Termination Fee, by wire transfer of immediately available funds to an account or accounts designated in writing by Parent, within two (2) Business Days after demand by Parent, in the event that (A) this Agreement is terminated by Parent or the Company pursuant to Section 9.1(b) as a result of the failure to satisfy the Minimum Condition prior to such termination (provided, that (x) the condition to the Offer set forth in clause (A) of Annex A is satisfied at the time of such termination pursuant to Section 9.1(b), (y) the condition to the Offer set forth in clause (C)(1) of Annex A is satisfied at the time of such termination pursuant to Section 9.1(b), except where the failure to meet such condition arises out of or results from a Legal Proceeding brought by or on behalf of the Person who has made the bona fide Acquisition Proposal referred to in clause (B) below and (z) the right to terminate this Agreement pursuant to Section 9.1(b) is then available to Parent); (B) following the execution and delivery of this Agreement and prior to such termination of this Agreement, a bona fide Acquisition Proposal shall have been publicly announced or shall have become publicly disclosed and, in either case, shall not have been withdrawn or otherwise abandoned; and (C) within twelve (12) months following such termination of this Agreement, the Company enters into a definitive agreement with any Person (other than Parent, Acquisition Sub, or their Affiliates) with respect to an Acquisition Proposal or an Acquisition Proposal is consummated. For purposes of the foregoing, each reference to “25%” in the definition of “Acquisition Proposal” shall be deemed to be a reference to “50%”.
(ii) In the event that this Agreement is terminated by the Company pursuant to Section 9.1(e), the Company shall pay to Parent the Termination Fee, within two (2) Business Days after demand by Parent, by wire transfer of immediately available funds to an account or accounts designated in writing by Parent.
(iii) In the event that this Agreement is terminated by Parent pursuant to Section 9.1(f), the Company shall pay to Parent the Termination Fee, within two (2) Business Days after demand by Parent, by wire transfer of immediately available funds to an account or accounts designated in writing by Parent.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Xxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Termination Fees (a) If, but only if, the Agreement is terminated by:
(i) either Parent or the Company pursuant to Section 7.1(b)(i) or by Parent pursuant to Section 7.1(d)(i) and (A) a Competing Proposal has been made to the Company after the date hereof and has not been withdrawn prior to the termination of this Agreement, and (B) within twelve (12) months after the termination of this Agreement, the Company (1) enters into a definitive agreement for the consummation of a Competing Proposal and such Competing Proposal is subsequently consummated (regardless of whether such consummation occurs within the twelve (12) month period) or (2) consummates a Competing Proposal, then the Company shall pay, or cause to be paid, to Parent the Termination Fee concurrently with the consummation of such transaction arising from such Competing Proposal (provided, however, that for purposes of this Section 7.3(a)(i), the references to “twenty percent (20%)” in the definition of Competing Proposal shall be deemed to be references to “fifty percent (50%)”);
(ii) the Company pursuant to Section 7.1(c)(ii), then the Company shall pay, or cause to be paid, to Parent the Termination Fee concurrently with such termination;
(iii) Parent pursuant to Section 7.1(d)(ii) or Section 7.1(d)(iii), then the Company shall pay, or cause to be paid, to Parent the Termination Fee not later than the second (2nd) Business Day following such termination; or
(iv) the Company pursuant to Section 7.1(c)(v), and within twelve (12) months after the termination of this Agreement, the Company (1) enters into a definitive agreement for the consummation of a Competing Proposal and such Competing Proposal is subsequently consummated (regardless of whether such consummation occurs within the twelve (12) month period) or (2) consummates a Competing Proposal, then the Company shall pay, or cause to be paid, to Parent the Termination Fee concurrently with the consummation of such transaction arising from such Competing Proposal (provided, however, that for purposes of this Section 7.3(a)(iv), the references to “twenty percent (20%)” in the definition of Competing Proposal shall be deemed to be references to “fifty percent (50%)”).
(b) Notwithstanding anything to the contrary set forth in this Agreement, the parties agree that in no event shall the Company or Parent be required to pay the Termination Fee on more than one occasion.
(c) Each of the parties hereto acknowledges that (i) the agreements contained in this Section 7.3 are an integral part of the Transactions, (ii) the Termination Fee is not a penalty but a reasonable amount that will compensate Parent in the circumstances in which such fee is payable for the efforts and resources expended and opportunities foregone while negotiating this Agreement and in reliance on this Agreement and on the expectation of the consummation of the Transactions, which amount would otherwise be impossible to calculate with precision, and (iii) without these agreements, the parties would not enter into this Agreement; accordingly, if the Company fails to timely pay any amount due pursuant to this Section 7.3 and, in order to obtain such payment, Parent commences a suit that results in a judgment against the Company or its successors for the payment of any amount set forth in this Section 7.3, the Company or its successors shall pay Parent its reasonable, documented out-of-pocket costs and expenses in connection with such suit, together with interest on such amount at the annual rate of five percent (5%) plus the prime rate as published in The Wall Street Journal in effect on the date such payment was required to be made through the date such payment was actually received, or such lesser rate as is the maximum permitted by applicable Law.
