Closing Date Delivery 2 2.1 Closing.........................................................................................2
Delivery of the Goods 19.1 Unless otherwise expressly specified in the written acknowledgement of order, delivery of the Goods will be made ex-works as defined in INCOTERMS 2000.
19.2 Delivery of the Goods will be made during Supplier’s usual business hours.
19.3 Supplier will use reasonable endeavours to deliver and perform each of Buyer’s orders for the Goods within the time agreed when Buyer places an order and Supplier provides the acknowledgement of order and, if no time is agreed, then within a reasonable time, but the time of delivery will not be of the essence. If, despite those endeavours, Supplier is unable for any reason to fulfil any delivery on the specified date, Supplier will be deemed not to be in breach of this Contract, nor (for the avoidance of doubt) will Supplier have any Liability to Buyer for any delay or failure in delivery except as set out in this condition. Any delay in delivery will not entitle Buyer to cancel the Contract unless and until Buyer has given one hundred and twenty days’ written notice (or such longer period specified in the written acknowledgement of Contract) to Supplier requiring the delivery to be made and Supplier has not fulfilled the delivery within that period. If Buyer cancels the Contract in accordance with this clause then:
19.3.1 Supplier will refund to Buyer any sums which Buyer has paid to Supplier in respect of that Contract or part of the Contract which has been cancelled and has not been delivered or is not ready for delivery; and
19.3.2 Buyer will be under no liability to make any further payments under clause 4.1 in respect of that Contract or part of the Contract which has been cancelled.
19.4 Buyer will provide at its expense at the Delivery Point adequate and appropriate equipment and manual labour for loading the Goods.
19.5 If Buyer fails to take delivery of any of the Goods when they are ready for delivery or to provide any instructions, documents, licences or authorisations required to enable the Goods to be delivered on time (except solely on account of Supplier’s default), the Goods will be deemed to have been delivered on the due date and (without prejudice to its other rights) Supplier may:
19.5.1 store or arrange for storage of the Goods until actual delivery or sale in accordance with this clause and charge Buyer for all related costs and expenses (including, without limitation, storage and insurance); and/or
19.5.2 following written notice to Buyer, sell any of the Goods at the best price reasonably obtainable in the circumstances and charge Buyer for any shortfall below the price under the Contract or account to Buyer for any excess achieved over the price under the Contract, in both cases having taken into account any charges related to the sale.
19.6 Buyer shall provide or procure the provision to Supplier of all facilities and such other assistance and services as may be necessary to the extent and quality necessary to enable Supplier to fulfil its obligations under the Contract. This assistance shall include (but not be limited to) the timely provision of and access to information, data, accommodation, computing resources, appropriate Buyer employees and a safe working environment.
Purchaser Deliverables The Purchaser shall have delivered its Purchaser Deliverables in accordance with Section 2.2(b).
Seller Closing Deliverables Seller shall have delivered to Purchaser each of the certificates, instruments, agreements, documents and other items required to be delivered pursuant to Section 3.5 at or prior to the Closing Date.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Delivery Time Vendors shall specify the estimated delivery time in calendar days for each item. The purchaser should consult the vendor regarding vehicle production schedules. Delivery shall be within the normal working hours of the user, Monday through Friday, excluding holidays.
Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.
Project Delivery Order Procedures Status of TIPS Members as Related to This Agreement
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
Delivery at Closing At the Closing, the Company will deliver to the Purchaser a stock certificate registered in the Purchaser’s name, representing the number of Shares to be purchased by Purchaser hereunder, against payment of the purchase price therefore as indicated above.
