Partial Condemnation In the event of a Condemnation of less than the whole of any Property such that such Property is still suitable for its Permitted Use, Tenant shall, to the extent of the Award and any additional amounts disbursed by Landlord as hereinafter provided, commence (or cause to be commenced) promptly and continue diligently to restore (or cause to be restored) the untaken portion of the applicable Leased Improvements so that such Leased Improvements shall constitute a complete architectural unit of the same general character and condition (as nearly as may be possible under the circumstances) as such Leased Improvements existing immediately prior to such Condemnation, in material compliance with all Legal Requirements, subject to the provisions of this Section 11.2. If the cost of the repair or restoration of the affected Property exceeds the amount of the Award, Tenant shall give Landlord Notice thereof which notice shall set forth in reasonable detail the nature of such deficiency and whether Tenant shall pay and assume the amount of such deficiency (Tenant having no obligation to do so, except that if Tenant shall elect to make such funds available, the same shall become an irrevocable obligation of Tenant pursuant to this Agreement). In the event Tenant shall elect not to pay and assume the amount of such deficiency, Landlord shall have the right (but not the obligation), exercisable at Landlord’s sole election by Notice to Tenant given within sixty (60) days after Tenant’s Notice of the deficiency, to elect to make available for application to the cost of repair or restoration the amount of such deficiency; provided, however, in such event, upon any disbursement by Landlord thereof, the Minimum Rent shall be adjusted as provided in Section 3.1.1(c). In the event that neither Landlord nor Tenant shall elect to make such deficiency available for restoration, either Landlord or Tenant may terminate this Agreement with respect to the affected Property and the entire Award shall be allocated as set forth in Section 11.5. Subject to the terms hereof, Landlord shall contribute to the cost of restoration that part of the Award necessary to complete such repair or restoration, together with severance and other damages awarded for the taken Leased Improvements and any deficiency Landlord has agreed to disburse, to Tenant regularly during the restoration period so as to permit payment for the cost of such repair or restoration. Landlord may, at its option, condition advancement of such Award and other amounts on (a) the absence of any Event of Default, (b) its approval of plans and specifications of an architect satisfactory to Landlord (which approval shall not be unreasonably withheld, delayed or conditioned), (c) general contractors’ estimates, (iv) architect’s certificates, (d) conditional lien waivers of general contractors, if available, (e) evidence of approval by all governmental authorities and other regulatory bodies whose approval is required, (f), if Tenant has elected to advance deficiency funds pursuant to the preceding paragraph, Tenant depositing the amount thereof with Landlord and (g) such other certificates as Landlord may, from time to time, reasonably require. Landlord’s obligation under this Section 11.2 to disburse the Award and such other amounts shall be subject to (x) the collection thereof by Landlord and (y) the satisfaction of any applicable requirements of any Facility Mortgage, and the release of such Award by the applicable Facility Mortgagee. Tenant’s obligation to restore the Leased Property shall be subject to the release of the Award by the applicable Facility Mortgagee to Landlord.
Total Condemnation If all of the Premises is condemned by eminent domain, inversely condemned or sold under threat of condemnation for any public or quasi-public use or purpose ("Condemned"), this Lease shall terminate as of the earlier of the date the condemning authority takes title to or possession of the Premises, and Rent shall be adjusted to the date of termination.
Condition of Property; Condemnation In the case of each Mortgage Loan, except as set forth in an engineering report prepared by an independent engineering consultant in connection with the origination of such Mortgage Loan, the related Mortgaged Property is, to the Seller's knowledge, in good repair and free and clear of any damage that would materially and adversely affect its value as security for such Mortgage Loan (except in any such case where an escrow of funds, letter of credit or insurance coverage exists sufficient to effect the necessary repairs and maintenance). As of the date of origination of the Mortgage Loan, there was no proceeding pending for the condemnation of all or any material part of the related Mortgaged Property. As of the Closing Date, the Seller has not received notice and has no knowledge of any proceeding pending for the condemnation of all or any material portion of the Mortgaged Property securing any Mortgage Loan. As of the date of origination of each Mortgage Loan and, to the Seller's knowledge, as of the date hereof, (a) none of the material improvements on the related Mortgaged Property encroach upon the boundaries and, to the extent in effect at the time of construction, do not encroach upon the building restriction lines of such property, and none of the material improvements on the related Mortgaged Property encroached over any easements, except, in each case, for encroachments that are insured against by the lender's title insurance policy referred to in representation 8 below or that do not materially and adversely affect the Value or current use of such Mortgaged Property and (b) no improvements on adjoining properties encroached upon such Mortgaged Property so as to materially and adversely affect the Value of such Mortgaged Property, except those encroachments that are insured against by the lender's title insurance policy referred to in representation 8 below.
Damage or Destruction Condemnation (a) In the event the Assigned Space or the improvements thereon are damaged by any casualty which is required to be insured against by Permittee pursuant to this Permit, then Permittee shall, in accordance with all applicable requirements of this Permit (including without limitation Section 1(2) above), repair such damage (and replace any Trade Equipment damaged by such casualty) as soon as reasonable possible, at its own cost, and this Permit shall continue in full force and effect, with no abatement in the Rent payable by Permittee to Port under Paragraph E of this Permit.
(b) In the event the Assigned Space or the improvements thereon are damaged by any casualty which is not required to be insured against by Permittee pursuant to the provisions of this Permit, then Port may, at Port’s option, either (i) repair such damage as soon as reasonably possible at Port’s expense, in which event this Permit shall continue in full force and effect, and there shall be no abatement in the Rent payable by Permittee to Port under Paragraph E of this Permit, or (ii) give written notice to Permittee within sixty (60) days after the date of occurrence of such damage of Port’s intention to terminate this Permit, in which event such termination shall be effective as of the date of the occurrence of such damage; provided, however, that notwithstanding the foregoing: (x) If such damage was caused by the act or omission of Permittee or any principal, affiliate, contractor, employee, agent, licensee or invitee of Permittee, then Permittee shall, in accordance with all applicable provisions of this Permit (including without limitation Section 1(2) above), repair such damage promptly and at its sole cost and expense, this Permit shall remain in full force and effect, and there shall be no abatement in the Rent payable by Permittee to Port under Paragraph E above; and (y) If such damage is not covered by subsection (b)(ii)(x) above, and if such damage occurred during the last twelve months of the Term, then either party shall have the right, by written notice given to the other within sixty (60) days after the date of occurrence of such damage, to terminate this Permit as of the date of such damage, in which event all proceeds of the insurance against casualty that Permittee was required to maintain pursuant to this Permit shall be paid to Port.
(c) If the Assigned Space is damaged or destroyed by casualty, Permittee shall have no claim against Port for any damage suffered by reason of any such damage or destruction, or for any required repair or restoration. Port and Permittee hereby waive the provisions of California Civil Code Sections 1932 and 1933, and of any other statutes which relate to the termination of a Permit when leased property is destroyed and agree that any such event shall be governed by the terms of this Permit.
(a) If the whole of the Assigned Space should be taken by any public or quasi-public authority under the power or threat of eminent domain, then, in such event, on the earlier of the date title to the Assigned Space vests in such public or quasi-public authority, or the date on which said public or quasi-public agency takes possession of the Assigned Space, this Permit shall terminate with respect to Port’s and Permittee’s future obligations hereunder, but said termination shall not affect Port’s and Permittee’s rights to any compensation or damages for, on the account of, or arising out of such taking. For any period of time prior to termination during which Permittee (involuntarily on account of such taking or any proceedings related thereto) does not have full use of the Assigned Space, the monthly Rent due hereunder shall be equitably reduced. In the event of such a taking, the Port shall be entitled to receive all sums in the award of damages and compensation arising by reason of such taking except that an amount therefrom equal to the fair market value of Permittee’s leasehold interest in the Assigned Space (as of the date of valuation of the taking) shall be paid to Permittee.
(b) If a substantial portion of the Assigned Space should be taken so as to impair materially the use of the Assigned Space as contemplated by the Permit, then on the earlier of the date title to such portion of the Assigned Space vests in such public or quasi-public agency, or the date on which such public or quasi-public agency takes possession of such portion of the Assigned Space and Permittee no longer has full possession of such portion, this Permit shall terminate with respect to Port’s and Permittee’s future obligations hereunder, but said termination shall not affect Port’s or Permittee’s rights to any compensation or damages for, on account of, or arising out of such taking. For any period of time prior to termination during which Permittee (involuntarily on account of such taking or any proceedings related thereto) does not have full use of the Assigned Space, the monthly Rent due hereunder shall be equitably reduced. In the event of such a substantial taking, the award of damages and compensation arising by reason of such taking shall be distributed in the same manner as the last sentence of Section 37(2)(a) above.
(c) If a taking shall occur which does not result in termination of this Permit as provided in the previous subsections of this Section 37(2), but which requires the portion of the Assigned Space not so taken to be reconstructed and restored so as to be constituted an architecturally complete unit suitable for use by Permittee, all compensation and damages payable for or on account of such taking shall be payable to Permittee, and shall be held in a separate account approved in writing by Port in trust by Permittee to be used by Permittee in accordance with all applicable requirements of this Permit (including without limitation Section 1(2) above) solely to reconstruct and restore the portion of the Assigned Space not so taken to an architecturally complete unit suitable for use by Permittee; and the monthly Rent payable by Permittee hereunder shall be equitably reduced during the time Permittee does not have full use of the Assigned Space as a result of such taking to account for the reduced economic value to Permittee, if any, occasioned by reason of such taking. The balance of any compensation and damages remaining after the reconstruction and restoration contemplated by this subsection shall be distributed in the same manner as distribution of damages and compensation for a total taking under the last sentence of Section 37(2)(a) above. In the event of a taking covered by this subsection (c), Port shall send to Permittee an amendment to this Permit showing the deletion of that portion of the Assigned Space that was the subject of this taking, and this Permit shall be deemed amended thereby.
(d) If a taking shall occur which does not result in a termination of this Permit as provided in the previous subsections of this Section 37(2), and which does not require any portion of the Assigned Space not so taken to be reconstructed and restored so as to constitute an architecturally complete unit suitable for use by Permittee, the proceeds shall be distributed in accordance with the last sentence of Section 37(2)(a) above. Permittee, however, shall be entitled to an equitable reduction in the monthly Rent.
(e) No taking of Permittee’s leasehold estate in the Assigned Space or any part thereof without a taking of the fee shall terminate or give Permittee the right to surrender this Permit, nor excuse the taker of such leasehold estate, including any successor in interest thereto, from full performance of the covenants for the payment of the Rent and other charges or any other obligations hereunder capable of performance by the taker of such leasehold estate, including any successor in interest thereto, after any such taking, but in such case, all compensation and damages payable for or on account of such taking shall be payable to and be the sole property of Port. During any period of time that Permittee is not in possession of the Assigned Space, or any portion thereof, as a result of the taking of any portion of its leasehold estate hereunder, but only during such period of time, (1) Permittee shall not be obligated to pay or in any way be liable for the payment of any Rent or to perform any of the other obligations or covenants otherwise to be performed by it hereunder with respect to, but only with respect to the portion of the Assigned Space affected by such taking, (2) the Port shall look solely to the taker of such leasehold interest, including the successors in interest thereto and any party then in possession of all or such portion of the Assigned Space affected by such taking for the payment of the Rent and the performance of the other obligations and covenants hereunder with respect to such portion of the Assigned Space, and (3) as between Port and Permittee, Port shall not forfeit or terminate this Permit for breach by the taker of such leasehold interest, including its successors in interest thereto and any party then in possession, of any obligation or covenant hereunder, including the obligation to pay the Rent. Any taking that is the subject of this subsection (e) shall not extend the Term of this Permit.
(f) In the event of any taking of any portion of the Assigned Space, Permittee shall be entitled to receive all compensation and damages arising from such taking and payable for or on account of the Permittee’s Trade Equipment located on the portion of the Assigned Space so taken, except for those trade fixtures and equipment that pursuant to this Permit are to remain with the Assigned Space on surrender.
(g) Except as otherwise expressly provided in this Section 37(2), no taking shall reduce or xxxxx Permittee’s obligation to pay the Rent during the Term of this Permit. Where Section 37(2) expressly provides for a reduction in the Rent payable by Permittee, if the parties cannot agree on the amount of such reduction, the same shall be determined by Arbitration. Such arbitration shall be conducted in accordance with the Commercial Arbitration Rules of the American Arbitration Association. The arbitrators shall have no power to modify any of the provisions of this Permit and their jurisdiction is limited accordingly. Each party hereby consents to the entry of judgment by any court having jurisdiction in accordance with the arbitration decision. No change in the Arbitration Rules which would deprive a party of the rights to be represented by counsel, to present evidence or to cross-examine witnesses presented by the other party shall be effective in any arbitration proceeding arising out of this Permit. Any arbitration provided for herein shall be conducted in the Port’s offices in Alameda County, California. Disputes under this Permit shall be subject to Arbitration only to the extent expressly provided for in this subsection (h).
(h) Permittee acknowledges the Port’s reserved power upon payment of just compensation to exercise its power of eminent domain as to the leasehold estate created hereunder; provided, however, that the foregoing acknowledgment shall not be deemed or construed to prejudice or waive any rights of Permittee to challenge or object to any attempt by the Port so to exercise such power.
EMINENT DOMAIN/CONDEMNATION 7.1 Lessor to notify Lessee 7.2 Whole taking, rents prorated 7.3 Taking
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Condemnation/Eminent Domain In the event the whole of the Premises, and/or such part thereof as shall substantially interfere with Tenant’s use and occupation thereof, shall be taken for any public or quasi-public purpose by any lawful power or authority by exercise of the right of appropriation, condemnation or eminent domain, or is sold in lieu of or to prevent such taking, then Landlord and Tenant shall each have the right to terminate this Lease (by written notice to the other given no later than 10 days after Landlord notifies Tenant of such taking) effective as of the date possession is required to be surrendered to said authority. In the event any access points to adjoining streets, shall be taken for any public or quasi-public purpose by any lawful power or authority by exercise of the right of appropriation, condemnation or eminent domain, or is sold in lieu of or to prevent such taking, and such taking shall substantially interfere with Tenant’s use of the Premises, then Landlord or Tenant shall each have the right to terminate this Lease effective as of the date possession is required to be surrendered to said authority. Except as provided below, Tenant shall not assert any claim against Landlord or the taking authority for any compensation because of such taking, and Landlord shall be entitled to receive the entire amount of any award without deduction for any estate or interest of Tenant in the Premises. Nothing contained in this Article 12 shall be deemed to give Landlord any interest in any separate award made to Tenant for the taking of personal property and fixtures belonging to Tenant or for Tenant’s moving expenses. In the event the amount of property or the type of estate taken shall not substantially interfere with the conduct of Tenant’s business, Landlord shall be entitled to the entire amount of the award without deduction for any estate or interest of Tenant, Landlord shall promptly proceed to restore the Building to substantially their same condition prior to such partial taking less the portion thereof lost in such condemnation (but in no event shall Landlord be obligated to incur costs in such restoration in excess of the amount of the award paid to Landlord, after deducting Landlord’s reasonable costs in connection therewith), and the Base Rent shall be proportionately reduced by the time during which, and the portion of the Premises which, Tenant shall have been deprived of possession on account of said taking and restoration.
Mortgaged Property Undamaged; No Condemnation Proceedings There is no proceeding pending or threatened for the total or partial condemnation of the Mortgaged Property. The Mortgaged Property is undamaged by waste, fire, earthquake or earth movement, windstorm, flood, tornado or other casualty so as to affect adversely the value of the Mortgaged Property as security for the Mortgage Loan or the use for which the premises were intended and each Mortgaged Property is in good repair. There have not been any condemnation proceedings with respect to the Mortgaged Property and the Seller has no knowledge of any such proceedings in the future;
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Casualty; Condemnation (a) If any condemnation or conveyance in lieu thereof of all or any portion of the Real Property occurs or is threatened prior to Closing (written notice of which shall be given to Purchaser by Seller promptly upon its receipt), Purchaser may at its option, either (i) terminate this Agreement by written notice to Seller given within twenty (20) days after Purchaser is notified of such actual or possible proceedings (but before the Closing), in which case all of the Escrow Funds shall be returned to Purchaser and all further rights and obligations of the parties under this Agreement shall terminate, except those expressly stated to survive termination, or (ii) proceed to Closing without abatement of the Purchase Price, in which case all proceeds or award (less any expenses incurred by Seller) shall be assigned to Purchaser. If any condemnation or conveyance in lieu thereof is presently pending or occurs after the date hereof, Seller shall not settle or agree to accept any compensation for same without Purchaser’s prior written consent, not to be unreasonably withheld.
(b) In the event of loss or damage to the Property or any portion thereof which is not “major” (as hereinafter defined), this Agreement shall remain in full force and effect, and neither Purchaser nor Seller shall have the right to terminate this Agreement and the parties shall nonetheless consummate this transaction in accordance with this Agreement, without any abatement of the Purchase Price or any liability or obligation on the part of Seller by reason of said damage except as set forth in the next sentence. In such event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(c) In the event of a “major” loss or damage to the Property or any portion thereof, Purchaser may terminate this Agreement by written notice to Seller, in which event the Escrow Funds shall be returned to Purchaser. If Purchaser does not give written notice of termination of this Agreement within twenty (20) days after Seller sends Purchaser written notice of the occurrence of major loss or damage, then Purchaser shall be deemed to have elected to proceed with Closing, in which event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(d) For purposes of this Section 12, “major” loss or damage refers to loss or damage to the Property or any portion thereof: (i) such that the cost of repair or restoration of the damage to a condition substantially identical to that prior to the event of damage would be, either be equal to or greater than $500,000 or require more than 120 days after the loss or damage to repair and restore, as determined by an independent appraiser chosen by Purchaser and reasonably acceptable to Seller, or (ii) having a material adverse impact upon the ability or feasibility of operating a nursing home facility on the Property, in substantially the same manner as the Property is being operated by Seller on the date hereof. Within ten (10) days after its occurrence, Seller shall give Purchaser written notice of any casualty and, if then available, an estimate of the restoration costs and time for restoration.
