Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to Object Any Person who has not requested exclusion from the Settlement Class and who objects to the settlement may appear in person or through counsel, at that Person’s own expense, at the Fairness Hearing to present any evidence or argument that the Court deems proper and relevant. However, no such Person shall be heard, and no papers, briefs, pleadings, or other Documents submitted by any such Person shall be received and considered by the Court, unless such Person properly submits a written objection that includes: (a) a notice of intention to appear; (b) proof of membership in the Settlement Class; and (c) the specific grounds for the objection and any reasons why such Person desires to appear and be heard, as well as all Documents or writings that such Person desires the Court to consider. Such a written objection must be both filed with the Court no later than thirty (30) days prior to the date set for the Fairness Hearing and mailed to Settlement Class Counsel and Settling Defendants’ Counsel at the addresses provided in the Class Notice and postmarked (or mailed by overnight delivery) no later than thirty (30) days prior to the date of the Fairness Hearing. Any Person who fails to object in the manner prescribed herein shall be deemed to have waived its objections and will forever be barred from making any such objections in the Actions or in any other action or proceeding, unless otherwise excused for good cause shown as determined by the Court.
OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.
City's Right to Proceed In the event this contract is terminated pursuant to Paragraph 8, then the City may take over the work and prosecute the same to completion, by contract or otherwise, and Contractor and its sureties shall be liable to the City for any costs over the amount of this contract thereby occasioned by the City. In any such case, the City may take possession of, and utilize in completing the work, such materials, appliances and structures as may be on the work site and are necessary for completion of the work. The foregoing provisions are in addition to, and not in limitation of, the rights of the City under any other provisions of the contract, city ordinances, and state and federal laws.
Contractor’s Right to Terminate for Cause Contractor may terminate this Contract immediately upon written notice to Agency, or at such later date as Contractor may establish in such notice, if Agency is in default under Section 14.4.
City’s Right to Reject The City reserves the right to reject a certificate of insurance if Contractor’s insurance company is widely regarded in the insurance industry as financially unstable. This would include but is not limited to insurance companies with no less than AVIII rating in the A.M. Best insurance rating guide.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
OWNER’S RIGHT TO CLEAN UP If a dispute arises among the Design-Builder, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and will allocate the cost among those responsible.
Agency’s Right to Audit A. Performing Agency shall make available at reasonable times and upon reasonable notice, and for reasonable periods, work papers, reports, books, records, supporting documents kept current by Performing Agency pertaining to the Contract for purposes of inspecting, monitoring, auditing, or evaluating by System Agency and the State of Texas.
