Professional Meetings Employees should be encouraged to and may, with the approval of the supervisor, attend professional meetings, conferences, and activities. Subject to the availability of funds, the employee's expenses in connection with such meetings, conferences, or activities shall be reimbursed in accordance with the applicable provisions of State law and university rules.
Compensation of Directors Directors on the Board shall not be entitled to receive a fee for the director’s services as a director on the Board.
FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.
Compensation of Directors; Expenses The Board shall have the authority to fix the compensation of Directors. The Directors may be paid their expenses, if any, of attendance at meetings of the Board, which may be a fixed sum for attendance at each meeting of the Board or a stated salary as Director. No such payment shall preclude any Director from serving the Company in any other capacity and receiving compensation therefor. Members of special or standing committees may be allowed like compensation for attending committee meetings.
REFUND OF UNEARNED COMPENSATION The Party of the Second Part agrees to refund the Party of the First Part any compensation received for which no services were rendered. TERMINATION: This contract may be terminated by either party pursuant to law. OTHER CONDITIONS: Any subsequent contracts shall supersede the provisions of this contract. PARTIES: The Fort Xxxxx School District 100, Party of the First Part, and XXXXX XXXXX XXXXX Party of the Second Part, agree as follows:
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence: a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Compensation of Managers Except as may be expressly provided for herein or hereafter approved by the Member, no payment will be made by the Company to any Manager for the services of such Manager or any partner or employee of the Manager.
Remuneration of Directors The directors are entitled to the remuneration for acting as directors, if any, as the directors may from time to time determine. If the directors so decide, the remuneration of the directors, if any, will be determined by the shareholders. That remuneration may be in addition to any salary or other remuneration paid to any officer or employee of the Company as such, who is also a director.
ATTENDANCE AT MANDATORY MEETINGS/SCHOOL EVENTS Where an employee is required through clear direction by the board to attend work outside of regular working hours, the provisions of the local collective agreement regarding hours of work and compensation, including any relevant overtime/lieu time provisions, shall apply. Required attendance outside of regular working hours may include, but is not limited to school staff meetings, parent/teacher interviews, curriculum nights, Individual Education Plan and Identification Placement Review Committee meetings, and consultations with board professional staff.
Medical Care and Emergency Leave An employee is entitled to a leave of absence without pay because of any of the following: 1. A personal illness, injury or medical emergency. 2. The death, illness, injury or medical emergency of an individual described in this Article. 3. An urgent matter that concerns an individual described in this Article. For the purposes of this Article, the individuals referred to in this Article are: - the employee’s spouse - a parent, step-parent or xxxxxx parent of the employee or the employee’s spouse - a child, step-child or xxxxxx child of the employee or the employee’s spouse - a grandparent, step-grandparent, grandchild or step-grandchild of the employee or of the employee’s spouse - the spouse of a child of the employee - the employee’s brother or sister - a relative of the employee who is dependent on the employee for care or assistance. An employee who wishes to take leave under this section shall advise his or her Hospital that he or she will be doing so. If the employee must begin the leave before advising the Hospital, the employee shall advise the Hospital of the leave as soon as possible after beginning it. An employee is entitled to take a total of 10 days’ leave under this section each year. If an employee takes any part of a day as leave under this section, the Hospital may deem the employee to have taken one day’s leave on that day for the purposes of this Article. The Hospital may require an employee who takes leave under this section to provide evidence reasonable in the circumstances that the employee is entitled to the leave. Upon the conclusion of an employee’s leave under this Article, the Hospital shall reinstate the employee to the position the employee most recently held with the Hospital, if it still exists, or to a comparable position, if it does not.
