United Indemnification of Contractor Sample Clauses

United Indemnification of Contractor. United shall be liable for and hereby agrees to fully defend, release, discharge, indemnify, and hold harmless Contractor, Parent, and their respective directors, officers, employees and agents from and against any and all claims, demands, damages, liabilities, suits, judgments, actions, causes of action, losses, fines, penalties, costs and expenses of any kind, character or nature whatsoever, including attorneys’ fees, costs and expenses in connection therewith and expenses of investigation and litigation thereof, which may be suffered by, accrued against, charged to, or recoverable from Contractor, Parent or their respective directors, officers, employees or agents, including but not limited to, any such losses, costs and expenses involving (i) death or injury (including claims of emotional distress and other non-physical injury by passengers) to any person, including without limitation any of Contractor’s or United’s directors, officers, employees or agents (excluding Contractor as such an agent), (ii) loss of, damage to, or destruction of property including real, tangible and intangible property, and specifically including regulatory property such as route authorities, slots and other landing rights, including any loss of use of such property or (iii) damages due to delays in any manner, in each case arising out of, connected with or attributable to (x) the performance, improper performance, nonperformance or breach of any and all obligations to be undertaken by United or any of its directors, officers, employees or agents (excluding Contractor as such an agent) pursuant to this Agreement, but only to the extent that such performance, improper performance or nonperformance is due to gross negligence or willful misconduct, or (y) the operation, non-operation or improper operation of United’s aircraft, equipment or facilities (excluding, for the avoidance of doubt, Covered Aircraft and any equipment or facilities leased or subleased by United to Contractor or otherwise used by Contractor for the provision of Contractor Services to United) at any location, in each case excluding only claims, demands, damages, liabilities, suits judgments, actions, causes of action, losses, fines, penalties, costs and expenses (A) to the extent resulting from the negligence or willful misconduct of Contractor (including in its capacity as an agent of United, UCH or their respective directors, officers, agents or employees), Parent or their respective directors, officers, e...
Sample 1Sample 2Sample 3See All (6)
United Indemnification of Contractor. United shall be liable for and hereby agrees fully to defend, release, discharge, indemnify, and hold harmless Contractor, its subsidiaries and their respective directors, officers, employees, and agents (each a “Contractor Indemnitee”) from and against any and all third party (such third parties include Contractor Indemnitees other than Contractor) claims, demands, damages, liabilities, suits, judgments, actions, causes of action, losses, fines, penalties, costs and expenses of any kind, character or nature whatsoever, including reasonable attorneys’ fees, costs and expenses in connection therewith and expenses of investigation and litigation thereof, which may be suffered by, accrued against, charged to, or recoverable from any Contractor Indemnitee, including but not limited to, any such losses, costs and expenses involving (i) death or injury (including claims of emotional distress and other non-physical injury by passengers) to any person including any of Contractor Indemnitees’, United’s or United’s Parent’s directors, officers, employees or agents (excluding any Contractor Indemnitee as such an agent), (ii) loss of, damage to, or destruction of property (including any loss of use of such property including real, tangible and intangible property, and specifically including regulatory property such as route authorities, slots and other landing rights), and (iii) damages due to delays in any manner, in each case arising out of, connected with, or attributable to, (x) the performance, improper performance, or nonperformance of any and all obligations to be undertaken by United or any of its directors, officers, employees or agents (excluding any Contractor Indemnitee as such an agent) pursuant to this Agreement, (y) the operation, non-operation or improper operation of United’s aircraft, equipment or facilities (excluding Covered Aircraft and any equipment or facilities leased or subleased by United to Contractor) at any location, or (z) Contractor’s use of the United Marks or the Identification, in each case excluding only claims, demands, damages, liabilities, suits judgments, actions, causes of action, losses, fines, penalties, costs and expenses to the extent resulting from the negligence or willful misconduct of a Contractor Indemnitee, provided that if United, any of United’s affiliates, or a subcontractor retained by United to provide Ground Handling Services is acting directly in the capacity of a ground handler, then unless superseded by anothe...
Sample 1

Related to United Indemnification of Contractor

  • Indemnification of NCPS From and at all times after the date of this Escrow Agreement, Issuer shall, to the fullest extent permitted by law, defend, indemnify and hold harmless NCPS and each director, officer, employee, attorney, agent and affiliate of NCPS (collectively, the “Indemnified Parties”) against any and all actions, claims (whether or not valid), losses, damages, liabilities, costs and expenses of any kind or nature whatsoever (including without limitation reasonable attorneys’ fees, costs and expenses) incurred by or asserted against any of the Indemnified Parties from and after the date hereof, whether direct, indirect or consequential, as a result of or arising from or in any way relating to any claim, demand, suit, action or proceeding (including any inquiry or investigation) by any person, including without limitation Issuer and Broker whether threatened or initiated, asserting a claim for any legal or equitable remedy against any person under any statute or regulation, including, but not limited to, any federal or state securities laws, or under any common law or equitable cause or otherwise, arising from or in connection with the negotiation, preparation, execution, performance or failure of performance of this Escrow Agreement or any transactions contemplated herein, whether or not any such Indemnified Party is a party to any such action, proceeding, suit or the target of any such inquiry or investigation; provided, however, that no Indemnified Party shall have the right to be indemnified hereunder for any liability finally determined by a court of competent jurisdiction, subject to no further appeal, to have resulted from the gross negligence or willful misconduct of such Indemnified Party. Each Indemnified Party shall, in its sole discretion, have the right to select and employ separate counsel with respect to any action or claim brought or asserted against it, and the reasonable fees of such counsel shall be paid upon demand by the Issuer. The obligations of Issuer under this Section 9 shall survive any termination of this Escrow Agreement and the resignation or removal of NCPS.

  • Indemnification of Company Each Underwriter will severally and not jointly indemnify and hold harmless the Company, each of its directors and each of its officers who signs a Registration Statement and each person, if any, who controls the Company within the meaning of Section 15 of the Act or Section 20 of the Exchange Act (each, an “Underwriter Indemnified Party”), against any losses, claims, damages or liabilities to which such Underwriter Indemnified Party may become subject, under the Act, the Exchange Act, other Federal or state statutory law or regulation or otherwise, insofar as such losses, claims, damages or liabilities (or actions in respect thereof) arise out of or are based upon any untrue statement or alleged untrue statement of any material fact contained in any part of any Registration Statement, or in any Preliminary Prospectus, any Statutory Prospectus, the Prospectus, any “road show” as defined in Rule 433(h) of the Act or any Written Testing-the-Waters Communication or in any amendment thereof or supplement thereto, or arise out of or are based upon the omission or the alleged omission of a material fact required to be stated therein or necessary to make the statements therein not misleading, in each case to the extent, but only to the extent, that such untrue statement or alleged untrue statement or omission or alleged omission was made in reliance upon and in conformity with written information furnished to the Company by or on behalf of such Underwriter through the Representative specifically for use therein, and will reimburse any legal or other expenses reasonably incurred by such Underwriter Indemnified Party in connection with investigating or defending against any such loss, claim, damage, liability, action, litigation, investigation or proceeding whatsoever (whether or not such Underwriter Indemnified Party is a party thereto), whether threatened or commenced, based upon any such untrue statement or omission, or any such alleged untrue statement or omission as such expenses are incurred, it being understood and agreed that the only such information furnished by or on behalf of any Underwriter consists of the statements set forth under the heading “Underwriting”: (x) the sentence related to the Underwriter’s intention not to make sales to discretionary accounts and (y) the paragraphs related to stabilization, syndicate covering transactions and penalty bids, in the Preliminary Prospectus, the Statutory Prospectus and the Prospectus constitute the only information furnished in writing by or on behalf of the several Underwriters for inclusion in the documents referred to in the foregoing indemnity.

  • Indemnification of Client In the event that the Client or Masterworks becomes involved in any capacity in any action, proceeding, investigation, or inquiry in connection with any matter referred to in this Agreement, the Financial Adviser agrees to reimburse the Client or Masterworks for its legal and other expenses (including but not limited to the cost of any investigation and preparation as they are incurred by Client or Masterworks in connection therewith) if, and to the extent that (i) it shall be finally judicially determined by a court of competent jurisdiction that such action, proceeding, investigation, or inquiry arose out of the gross negligence or willful misconduct of Financial Adviser in performing the services, which are the subject of this Agreement; or (ii) such action, proceeding, investigation, or inquiry arose solely out of Financial Adviser’s violation of its representations and warranties set forth in this Agreement regarding compliance with securities laws. Financial Adviser also agrees to indemnify Client and hold it harmless from and against any and all losses, claims, damages, liabilities, costs, and expenses of every kind, nature, and description, fixed or contingent (including, without limitation, counsel’s fees and expenses and the costs of investigation and preparation for and any other costs associated with any action, proceeding, investigation or inquiry in which Client may be involved in any capacity) incurred by Client or Masterworks in connection with or as a result of any matter referred to in this Agreement or arising out of any matter contemplated by this Agreement if (i) it shall be finally judicially determined by a court of competent jurisdiction that such losses, claims, damages, or liabilities arose out of the gross negligence or willful misconduct of Financial Adviser; or, (ii) in the event of Financial Adviser’s violation of its representations and warranties set forth in this Agreement regarding compliance with securities laws.

  • Indemnification of City The Permittee shall indemnify, defend, save and hold harmless the City and its officers and employees, from and against all suits or claims that may be based upon any damage or injury or death, to any person or property that may occur, or that may be alleged to have occurred, in the course of the use of the Premises by the Permittee, and also whether such claims be made by an owner, officer, principal, employee, or a contractor or its employees, of the Permittee, or by any third party, also including Event and Festival licensees and vendors, their owners, principals, employees, and their contractors and contractor’s employees, and by members of the public, and whether or not it shall be claimed that the damage or injury or death was caused through the negligent act or omission in whole or in part of the City and/or its officers and/or employees. The Permittee shall indemnify, defend, save and hold harmless the City and its officers and employees, from and against all suits or claims that may be based upon any liability of the City, including such that may arise under U.S. Copyright Laws, to all music licensing agencies (including but not limited to SESAC, BMI and ASCAP) and any other third parties resulting from or accruing from Permittee’s unlicensed authorization, sponsoring or presenting recorded or live music on City property or in City buildings or facilities. The Permittee shall, at the Permittee’s own expense, pay all charges of attorneys, and all costs and other expenses arising therefrom or incurred in connection therewith, and if any judgment shall be rendered against the City and/or its officers and/or its employees in any such action, or actions, the Permittee, at the Permittee’s own expense, shall satisfy and discharge the same. The preceding shall not apply to require indemnification by Permittee for any liability, claims, suits, etc., arising from action by officers of the Bethlehem Police Department.

  • Indemnification of the QIU Without limitation and in addition to its obligation under the other subsections of this Section 5, the Company agrees to indemnify and hold harmless Odeon, in its capacity as the QIU, its directors, officers, agents, partners, members and employees and each Controlling Person from and against any and all loss, liability, claim, damage and expense, as incurred, arising out of or based upon the QIU’s acting as a “qualified independent underwriter” (within the meaning of Rule 5121 of the Rules of FINRA) in connection with the Offering contemplated by this Agreement, and agrees to reimburse each such indemnified person for any legal or other expense reasonably incurred by them in connection with investigating, defending, settling, compromising or paying any such loss, claim, damage, liability, expense or action; provided, however, that the Company shall not be liable in any such case to the extent that any such loss, claim, damage, liability or expense results from the gross negligence or willful misconduct of the QIU. Notwithstanding the indemnification set forth in this Section 5.1.5, Odeon will undertake liability under Section 11 of the Exchange Act for acting as a qualified independent underwriter in connection with this Offering in compliance with FINRA Rule 5121(f)(12)(C).

  • Additional Indemnification; Limitation of Liability A. Subject to Section 2(A), USBFS CANNOT AND DOES NOT GUARANTEE AVAILABILITY OF THE ELECTRONIC SERVICES. Accordingly, USBFS’s sole liability to the Trust or any third party (including End Users) for any claims, notwithstanding the form of such claims (e.g., contract, negligence, or otherwise), arising out of the delay of or interruption in the Electronic Services to be provided by USBFS hereunder shall be to use its best reasonable efforts to commence or resume the Electronic Services as promptly as is reasonably possible. B. USBFS shall, at its sole cost and expense, defend, indemnify, and hold harmless the Trust and its trustees, officers and employees from and against any and all claims, demands, losses, expenses and liabilities of any and every nature (including reasonable attorneys’ fees) arising out of or relating to (a) any infringement, or claim of infringement, of any United States patent, trademark, copyright, trade secret, or other proprietary rights based on the use or potential use of the Electronic Services and (b) the provision of the Trust Files (as defined below) or Confidential Information (as defined below) to a person other than a person to whom such information may be properly disclosed hereunder. C. If an injunction is issued against the Trust’s use of the Electronic Services by reason of infringement of a patent, copyright, trademark, or other proprietary rights of a third party, USBFS shall, at its own option and expense, either (i) procure for the Trust the right to continue to use the Electronic Services on substantially the same terms and conditions as specified hereunder, or (ii) after notification to the Trust, replace or modify the Electronic Services so that they become non-infringing, provided that, in the Trust’s judgment, such replacement or modification does not materially and adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust. If in the Trust’s judgment, such replacement or modification does materially adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust, the Trust may terminate all rights and responsibilities under this Exhibit C immediately on written notice to USBFS. D. Because the ability of USBFS to deliver Electronic Services is dependent upon the Internet and equipment, software, systems, data and services provided by various telecommunications carriers, equipment manufacturers, firewall providers and encryption system developers and other vendors and third parties, USBFS shall not be liable for delays or failures to perform its obligations hereunder to the extent that such delays or failures are attributable to circumstances beyond its reasonable control which interfere with the delivery of the Electronic Services by means of the Internet or any of the equipment, software and services which support the Internet provided by such third parties. USBFS shall also not be liable for the actions or omissions of any third party wrongdoers (i.e., hackers not employed by USBFS or its affiliates) or of any third parties involved in the Electronic Services and shall not be liable for the selection of any such third party, unless USBFS selected the third party in bad faith or in a grossly negligent manner. E. USBFS shall not be responsible for the accuracy of input material from End Users nor the resultant output derived from inaccurate input. The accuracy of input and output shall be judged as received at USBFS’s data center as determined by the records maintained by USBFS. F. Notwithstanding anything to the contrary contained herein, USBFS shall not be obligated to ensure or verify the accuracy or actual receipt, or the transmission, of any data or information contained in any transaction via the Electronic Services or the consummation of any inquiry or transaction request not actually reviewed by USBFS.

  • Limitation of Liability; Indemnification (a) None of the Property Manager, its affiliates, or any of their respective directors, members, stockholders, partners, officers, employees or controlling persons (collectively, “Managing Parties”) shall be liable to the Company for (i) any act or omission performed or failed to be performed by any Managing Party (other than any criminal wrongdoing) arising from the exercise of such Managing Party’s rights or obligations hereunder, or for any losses, claims, costs, damages, or liabilities arising therefrom, in the absence of criminal wrongdoing, willful misfeasance or gross negligence on the part of such Managing Party, (ii) any tax liability imposed on the Company or the Asset, or (iii) any losses due to the actions or omissions of the Company or any brokers or other current or former agents or advisers of the Company. (b) To the fullest extent permitted by applicable law, the Company will indemnify the Property Manager and its Managing Parties against any and all losses, damages, liabilities, judgments, costs and expenses (including, without limitation, reasonable attorneys’ fees and disbursements) and amounts paid in settlement (collectively, “Losses”) to which such person may become subject in connection with any matter arising out of or in connection with this Agreement, except to the extent that any such Loss results solely from the acts or omissions of a Managing Party that have been determined in a final, non-appealable decision of a court, arbitrator or other tribunal of competent jurisdiction to have resulted primarily from such Managing Party’s fraud, willful misconduct or gross negligence. If this Section 5 or any portion hereof shall be invalidated on any ground by a court of competent jurisdiction, the Company shall nevertheless indemnify the Managing Party for any Losses incurred to the full extent permitted by any applicable portion of this Section that shall not have been invalidated. (c) The Property Manager gives no warranty as to the performance or profitability of the Asset or as to the performance of any third party engaged by the Property Manager hereunder. (d) The Property Manager may rely upon and shall be protected in acting or refraining from action upon any instruction from, or document signed by, any authorized person of the Company or other person reasonably believed by the Property Manager to be authorized to give or sign the same whether or not the authority of such person is then effective.

  • Unlawful Indemnification To indemnify the Indemnitee if a final decision by a court having jurisdiction in the matter shall determine that such indemnification is not lawful. In this respect, the Company and the Indemnitee have been advised that the Securities and Exchange Commission takes the position that indemnification for liabilities arising under the federal securities laws is against public policy and is, therefore, unenforceable and that claims for indemnification should be submitted to appropriate courts for adjudication.

  • LEGAL INDEMNIFICATION For the purposes of legal costs, it shall include those costs of an Association approved para-legal service. (A) Subject to the other provisions of this Article, a member charged with and finally acquitted of a criminal or statutory offence because of acts done in the performance or attempted performance of his employment or duties, shall be indemnified for the necessary and reasonable legal costs incurred in the defence of such charges. (B) Members shall not be indemnified for legal costs arising from the actions or omissions of members acting in their capacity as private citizens. For the purpose of Clause 29.1 (A) a Member: shall be deemed to have been "Finally Acquitted", where charges are withdrawn or where he is discharged following a preliminary inquiry; and shall be deemed not to have been "Finally Acquitted" where the member is given an absolute or conditional discharge or where, if as a result of charges laid he is subsequently found guilty of, or pleads guilty to, other charges arising out of the same incident or incidents. 29.2 When a member is a defendant in a civil action for damages because of acts done in the course of his employment or duties he shall be indemnified for the necessary and reasonable legal costs incurred in the defence of such an action in the following circumstances only: (i) where the Board is not joined in the action as a party pursuant to s. 50 of the Police Services Act, and the Board does not defend the action on behalf of itself and the member as joint tortfeasors at the Board's sole expense; (ii) where the Board is joined as a party or elects to defend the action, but the Solicitor retained on behalf of the Board and the member is of the view that it would be improper for him to act for both the Board and the member in that action. 29.3 Where during an inquest under the Coroner's Act a member's conduct is called into question because of acts done in the performance of his duties, the member shall be indemnified for any necessary and reasonable legal costs directly arising from the protection of the member's interest at such inquiry, but only if: (i) the Chief of Police or the Board does not provide counsel to represent the York Regional Police, at the Board's expense; or (ii) in the opinion of counsel retained by the Chief of Police or the Board to represent the York Regional Police, it would be improper for him to represent the member and the Chief and/or the Board before that inquiry. 29.4 To qualify for financial assistance under 29.1, 29.2 or 29.3, the member shall obtain the Board's approval of counsel to be retained by the member by application to the Board through the Chief. The Board's approval of counsel shall not be withheld unreasonably. 29.5 The Board will not consider any application for financial assistance which relates to the legal representation of a member in connection with a grievance or complaint made under the provisions of the Police Services Act, 1990 of this Collective Agreement or for the legal defence of a member resulting from a discipline charge made under the Police Services Act, 1990, Regulations made under that Act and all amendments thereto. 29.6 Where an investigation is commenced under Part VII of the Police Services Act and it appears to the Chief of Police that a member requires legal counsel in responding to the investigation, the Chief of Police may arrange for legal counsel to provide counsel to the member in connection with the investigation of such terms as the Chief considers appropriate. As soon as practicable, the Chief shall bring his action and his recommendation to the attention of the Board who may approve or alter the terms of retention of such legal counsel or the Chief's recommendation in respect thereof. Neither the Board nor the Chief shall provide legal counsel after the completion of the investigation or the laying of information(s), as Article 29 of the Civilian Collective Agreement is intended to govern such matters. 29.7 All sections under Article 29 (Legal Indemnification) are subject to review and re- negotiation by either the Board or the Association when the Regulations of the Police Services Act are proclaimed in force. If changes cannot be negotiated then either party reserves the right to submit the terms of this Article to arbitration. 29.8 A member who becomes involved in a matter which may entitle him/her to legal indemnification under this clause is entitled to receive funds from the Board for a retainer and/or for interim payment of legal costs as reasonably requested by the member’s counsel to a maximum of $5,000.00 provided the member undertakes to indemnify the Board for such funds advanced to him if the member is finally determined not to be eligible for indemnification in accordance with this Agreement.

  • Indemnification of Covered Persons Every Covered Person shall be indemnified by the Trust to the fullest extent permitted by the Delaware Act, the Bylaws and other applicable law.