Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.
Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
Termination Notice If either Party, having become entitled to do so, decides to terminate this Agreement pursuant to the preceding Clause 8.2 (a) (i) or 8.2 (a) (ii), it shall issue Termination Notice setting out: (i) in sufficient detail the underlying Force Majeure Event; (ii) the Termination Date which shall be a date occurring not earlier than 60 (sixty) days from the date of Termination Notice; (iii) the estimated Termination Payment including the details of computation thereof and; (iv) any other relevant information.
Cancellation Notice Each of the insurance policies will be specifically endorsed to require the insurer to provide the Authority with 30 days written notice (or 10 days for non-payment of premium) prior to the cancellation of the policy. The endorsement will specify that such notice will be sent to: Hillsborough County Aviation Authority Attn.: Chief Executive Officer Tampa International Airport Post Office Box 22287 Xxxxx, Xxxxxxx 00000
Termination Upon Notice Following thirty (30) days’ written notice, the State Entity may terminate the Contract in whole or in part without the payment of any penalty or incurring any further obligation to the Contractor. Following termination upon notice, the Contractor shall be entitled to compensation, upon submission of invoices and proper proof of claim, for goods and services provided under the Contract to the State Entity up to and including the date of termination.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Providing Notice of Breaches 8.1 If Covered Entity determines that an impermissible acquisition, access, use or disclosure of PHI for which one of Business Associate’s employees or agents was responsible constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity, Business Associate shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When requested to provide notice, Business Associate shall consult with Covered Entity about the timeliness, content and method of notice, and shall receive Covered Entity’s approval concerning these elements. The cost of notice and related remedies shall be borne by Business Associate. 8.2 If Covered Entity or Business Associate determines that an impermissible acquisition, access, use or disclosure of PHI by a Subcontractor of Business Associate constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity or Business Associate, Subcontractor shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When Covered Entity requests that Business Associate or its Subcontractor provide notice, Business Associate shall either 1) consult with Covered Entity about the specifics of the notice as set forth in section 8.1, above, or 2) require, by contract, its Subcontractor to consult with Covered Entity about the specifics of the notice as set forth in section 8.1 8.3 The notice to affected individuals shall be provided as soon as reasonably possible and in no case later than 60 calendar days after Business Associate reported the Breach to Covered Entity. 8.4 The notice to affected individuals shall be written in plain language and shall include, to the extent possible, 1) a brief description of what happened, 2) a description of the types of Unsecured PHI that were involved in the Breach, 3) any steps individuals can take to protect themselves from potential harm resulting from the Breach, 4) a brief description of what the Business Associate is doing to investigate the Breach, to mitigate harm to individuals and to protect against further Breaches, and 5) contact procedures for individuals to ask questions or obtain additional information, as set forth in 45 CFR § 164.404(c). 8.5 Business Associate shall notify individuals of Breaches as specified in 45 CFR § 164.404(d) (methods of individual notice). In addition, when a Breach involves more than 500 residents of Vermont, Business Associate shall, if requested by Covered Entity, notify prominent media outlets serving Vermont, following the requirements set forth in 45 CFR § 164.406.
Notice of Nonpayment The Trustee shall notify the Grantor and the Division by certified mail within 10 days following expiration of the 30-day period after the anniversary of the establishment of the Trust, if no payment is received from the Grantor during that period. After the pay-in period is completed, the Trustee shall not be required to send a notice of nonpayment.
Notice of Non-Renewal Consultant understands and agrees that there is no representation, implication, or understanding that the City will request that work product provided by Consultant under this agreement be supplemented or continued by Consultant under a new agreement following expiration or termination of this agreement. Consultant waives all rights or claims to notice or hearing respecting any failure by City to continue to request or retain all or any portion of the work product from Consultant following the expiration or termination of this agreement.
