Wage Adjustments If the funding available to be used for wages provided by Government in any fiscal year increases, the Employer shall pass on such increases to employees consistent with the funding increase adjusted for any additional deficits that this contract incurs. This will be the case whether the funding increase is for the entire year or simply a portion of it, and wage increases shall be effective upon the effective date of the increased funding. Should there be no increase provided by Government, wages will be maintained at their present levels. Should there be a decrease in funding, then the Employer will maintain wages at present levels. The Employer will promptly provide the Union with any information it receives from the Government regarding funding available for wages, and the parties will meet as required to work towards cooperative resolution of any issues arising from this Government information.
True-Up Adjustments From time to time, until the Retirement of the Recovery Bonds, the Servicer shall identify the need for True-Up Adjustments and shall take all reasonable action to obtain and implement such True-Up Adjustments, all in accordance with the following:
Market Adjustments Neither this Article nor any other in this Collective Agreement prevents the Employer from using other funds to increase a Member’s salary in response to offers received from other employers or to accommodate other market forces.
Cost Adjustments Both parties agree that contracted prices shall be fixed for the first 12 months of this Contract. Contractor must submit to District any proposed cost adjustments at least 60 days before the proposed effective date of such increases with a detailed explanation for each adjustment. District alone reserves the right to reject any changes to this Contract it deems unacceptable.
Fee Adjustments The fixed fees and other fees expressed as stated dollar amounts in this Schedule C and in this Agreement are subject to annual increases, commencing on the one-year anniversary date of the date of this Agreement, in an amount equal to the percentage increase in consumer prices for services as measured by the United States Consumer Price Index entitled “All Services Less Rent of Shelter,” or a similar index should such index no longer be published, since such one-year anniversary or since the date of the last fee increase, as applicable.
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
Royalty Adjustments The following adjustments shall be made, on a Licensed Product-by-Licensed Product and country-by-country basis, to the royalties payable pursuant to this Section 5.5:
Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Rate Adjustments 1. Taxes applicable to the gas delivered to Buyer hereunder as are in effect on January 1st immediately preceding the effective date of these terms and conditions shall be added to Buyer's bill. The term "taX- as used herein shall mean any tax, license fee, or charge applicable to the gas delivered hereunder, imposed on Seller by any governmental authority on such gas. If the existing rate of any such tax in effect on January 1st, immediately preceding the effective date of these terms and conditions, be hereafter increased or decreased, or if any tax heretofore in effect or hereafter be im posed or repealed . the resu lting increase or decrease in such taxes, computed on a cents per dekatherm basis. shall be reflected, as the case may be, on Xxxxx's bill. 2. Any applicable surcharge or special charges ordered by the Commission or any other duly constituted regulatorx body shall be·included in addition to the price of gas computed in accord ance with the terms of the Service Agreement.
Utility Adjustments DB Contractor shall not commence or permit or suffer commencement of construction of a Utility Adjustment included in the Construction Work until TxDOT issues NTP2, all of the conditions set forth in Section 4.4.1 that are applicable to the Utility Adjustment (reading such provisions as if they referred to the Utility Adjustment) have been satisfied, and the following additional requirements have been satisfied: (a) If applicable, the Alternate Procedure List has been approved by FHWA, and either the affected Utility or the Utility Owner is on the approved Alternate Procedure List, as supplemented. (b) The Utility Adjustment is covered by an executed Utility Agreement. (c) The review and comment process has been completed and any required approvals have been obtained for the Utility Assembly covering the Utility Adjustment.