Limited Waiver of Sovereign Immunity Ex Contractu Contractor acknowledges and agrees that Owner is an agency or instrumentality of the State of Georgia, and as such is entitled to the protection of sovereign immunity. As set forth in Article I, Section II, Paragraph IX of the 1983 Georgia Constitution, sovereign immunity is waived “as to any action ex contractu for the breach of any written contract.” Contractor specifically acknowledges the constitutional and contractual requirements that written changes, modifications, and waivers to this Contract must be specifically executed by the Owner as set forth in the Contract Documents. Accordingly, Contractor specifically acknowledges the constitutional prohibitions against claims against Owner based solely upon oral statement, course of conduct, customs of the trade, quasi-contract, quantum meruit, or O.C.G.A § 13-4-4 (mutual departure from contract terms).
Waiver of Appellate and Post-Conviction Rights a. The defendant acknowledges, understands and agrees that by pleading guilty pursuant to this plea agreement he waives his right to appeal or collaterally attack a finding of guilt following the acceptance of this plea agreement, except on grounds of (1) ineffective assistance of counsel; or (2) prosecutorial misconduct.
SHIPPING AND SHIPPING COSTS All delivered Equipment and Products must be properly packaged. Damaged Equipment and Products may be rejected. If the damage is not readily apparent at the time of delivery, Supplier must permit the Equipment and Products to be returned within a reasonable time at no cost to Sourcewell or its Participating Entities. Participating Entities reserve the right to inspect the Equipment and Products at a reasonable time after delivery where circumstances or conditions prevent effective inspection of the Equipment and Products at the time of delivery. In the event of the delivery of nonconforming Equipment and Products, the Participating Entity will notify the Supplier as soon as possible and the Supplier will replace nonconforming Equipment and Products with conforming Equipment and Products that are acceptable to the Participating Entity. Supplier must arrange for and pay for the return shipment on Equipment and Products that arrive in a defective or inoperable condition. Sourcewell may declare the Supplier in breach of this Contract if the Supplier intentionally delivers substandard or inferior Equipment or Products.
Waiver of Sovereign Immunity Each Loan Party that is incorporated outside the United States, in respect of itself, its Subsidiaries, its process agents, and its properties and revenues, hereby irrevocably agrees that, to the extent that such Loan Party or its respective Subsidiaries or any of its or its respective Subsidiaries’ properties has or may hereafter acquire any right of immunity, whether characterized as sovereign immunity or otherwise, from any legal proceedings, whether in the United States or elsewhere, to enforce or collect upon the Loans or any Loan Document or any other liability or obligation of such Loan Party or any of their respective Subsidiaries related to or arising from the transactions contemplated by any of the Loan Documents, including, without limitation, immunity from suit, immunity from service of process, immunity from jurisdiction or judgment of any court or tribunal, immunity from execution of a judgment, and immunity of any of its property from attachment prior to any entry of judgment, or from attachment in aid of execution upon a judgment, such Loan Party, for itself and on behalf of its Subsidiaries, hereby expressly waives, to the fullest extent permissible under applicable law, any such immunity, and agrees not to assert any such right or claim in any such proceeding, whether in the United States or elsewhere. Without limiting the generality of the foregoing, each Loan Party further agrees that the waivers set forth in this Section 10.25 shall have the fullest extent permitted under the Foreign Sovereign Immunities Act of 1976 of the United States and are intended to be irrevocable for purposes of such Act.
No Waiver of Sovereign Immunity Nothing in the Contract will be construed as a waiver of the System Agency’s or the State’s sovereign immunity. This Contract shall not constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas under the Contract or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. System Agency does not waive any privileges, rights, defenses, or immunities available to System Agency by entering into the Contract or by its conduct prior to or subsequent to entering into the Contract.
Shipping and Handling Fees The price to the Customer under this Contract shall include all shipping and handling fees. Shipments will be Free On Board Customer’s destination. No additional fees shall be charged to the Customer for standard shipping and handling. If the Customer requests expedited delivery, Customer will be responsible for any charges for expedited delivery.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Waiver of Rights No right conferred on either party under this Contract shall be deemed waived, and no breach of this Contract excused, unless such waiver is in writing and signed by the party claimed to have waived such right. Neither the State’s review, approval or acceptance of, nor payment for, the services required under this Contract shall be construed to operate as a waiver of any rights under this Contract or of any cause of action arising out of the performance of this Contract, and the Contractor shall be and remain liable to the State in accordance with applicable law for all damages to the State caused by the Contractor’s negligent performance of any of the services furnished under this Contract.
Waiver of Steps The parties may mutually agree to waive any step of the grievance procedure.
No Waiver of Sovereign Immunity or Powers Nothing in this agreement will be deemed to constitute a waiver of sovereign immunity or powers of licensee, the Xxxxxxxxxx County Commissioners Court, or the Xxxxxxxxxx County Judge.
