Warranty (GCC Clause 15) Sample Clauses

Warranty (GCC Clause 15). GCC 15.2—In accordance with the provisions, the warranty period shall be 2000 hours of operation or 12 months (parts and labor warranty) from date of Handing Over (Final Acceptance) of the Goods whichever occurs earlier. The Supplier shall, in addition, comply with the performance and/or consumption guarantees specified under the Contract. If, for reasons attributable to the Supplier, these guarantees are not attained in whole or in part, the Supplier shall, at its discretion, either: (a) Make such changes, modifications, and/or additions to the Goods or any part thereof as may be necessary in order to attain the contractual guarantees specified in the Contract at its own cost and expense and to carry out further performance tests in accordance with SCC 4, (b) Pay liquidated damages to the Purchaser with respect to the failure to meet the contractual guarantees. The rate of these liquidated damages shall be 0.1 % of the contract price per day. The maximum amount of liquidated damages for the whole of the goods or part thereof shall be 5% of the contract price. (c) Replacement of the whole unit at site including transportation, installation, testing & commissioning etc in case of major defect at his own cost.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
Warranty (GCC Clause 15). GCC 15.2—In accordance with the provisions, the warranty period shall be 2000 hours of operation or 12 months (parts and labor warranty) from date of Handing Over (Final Acceptance) of the Goods whichever occurs earlier. The Supplier shall, in addition, comply with the performance and/or consumption guarantees specified under the Contract. If, for reasons attributable to the Supplier, these guarantees are not attained in whole or in part, the Supplier shall, at its discretion, either:
Sample 1
Warranty (GCC Clause 15). GCC 15.2—In accordance with the provisions, the warranty period shall be 12 months (parts and labor warranty) from date of Handing Over (Final Acceptance) of the Goods whichever occurs later. The Supplier shall, in addition, comply with the performance and/or consumption guarantees specified under the Contract. If, for reasons attributable to the Supplier, these guarantees are not attained in whole or in part, the Supplier shall, at its discretion, either: (a) Make such changes, modifications, and/or additions to the Goods or any part thereof as may be necessary in order to attain the contractual guarantees specified in the Contract at its own cost and expense and to carry out further performance tests in accordance with SCC 4, (b) Pay liquidated damages to the Procuring Agency with respect to the failure to meet the contractual guarantees. The rate of these liquidated damages shall be
Sample 1

Related to Warranty (GCC Clause 15)

  • Survival Clause It is the intent of the Parties that this Agreement and procurement method applies to any TIPS Sale made during the life of this Agreement even if made on or near the Contract Expiration Date as defined herein. Thus, all TIPS Sales, including but not limited to: leases, service agreements, license agreements, open purchase orders, warranties, and contracts, even if they extend months or years past the TIPS Contract Expiration Date, shall survive the expiration or termination of this Agreement subject to the terms and conditions of the Supplemental Agreement between Customer and Vendor or unless otherwise specified herein.

  • CONTRACT CLAUSES  A SOLICITATION/CONTRACT FORM 1  I CONTRACT CLAUSES 58  B SUPPLIES OR SERVICES AND PRICES/COSTS 2 PART III - LIST OF DOCUMENTS, EXHIBITS & ATTACHMENTS  C DESCRIPTION/SPECS./WORK STATEMENT 25  J LIST OF ATTACHMENTS 74  D PACKAGING AND MARKING 26 PART IV - REPRESENTATIONS AND INSTRUCTIONS  E INSPECTION AND ACCEPTANCE 27 K REPRESENTATIONS, CERTIFICATIONS OTHER STATEMENTS OF OFFERORS  F DELIVERIES OR PERFORMANCE 29  G CONTRACT ADMINISTRATION DATA 32 L INSTRS., CONDS., AND NOTICES TO  H SPECIAL CONTRACT REQUIREMENTS 34 M EVALUATION FACTORS FOR AWARD

  • Warranty Disclaimer EXCEPT FOR THE LIMITED WARRANTIES STATED ABOVE, THE SOLUTIONS AND ALL RELATED SERVICES ARE PROVIDED “AS IS” AND CUSTOMER’S USE OF THEM IS AT ITS OWN RISK. AVEPOINT DOES NOT MAKE, AND HEREBY SPECIFICALLY DISCLAIMS, AND CUSTOMER RELEASES AND WAIVES, ANY AND ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, STATUTORY OR OTHERWISE OR FROM A COURSE OF DEALING, COURSE OF PERFORMANCE, USAGE OR TRADE PRACTICE, INCLUDING BUT NOT LIMITED TO WARRANTIES OF MERCHANTABILITY, TITLE, FITNESS FOR A PARTICULAR PURPOSE OR NONINFRINGEMENT. AVEPOINT DOES NOT WARRANT THAT CUSTOMER’S USE OF THE SOLUTIONS WILL BE UNINTERRUPTED OR ERROR- FREE, NOR DOES AVEPOINT WARRANT THAT IT WILL REVIEW CUSTOMER DATA FOR ACCURACY OR THAT IT WILL PRESERVE OR MAINTAIN CUSTOMER DATA WITHOUT LOSS. AVEPOINT SHALL NOT BE LIABLE FOR DELAYS, INTERRUPTIONS, SERVICE FAILURES OR OTHER PROBLEMS INHERENT IN USE OF THE INTERNET AND ELECTRONIC COMMUNICATIONS OR OTHER SYSTEMS OUTSIDE THE REASONABLE CONTROL OF AVEPOINT. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, AVEPOINT DOES NOT WARRANT THAT THE SOLUTIONS WILL MEET CUSTOMER’S REQUIREMENTS, WILL OPERATE IN ANY COMBINATION THAT MAY BE SELECTED FOR USE BY CUSTOMER OR IN COMBINATION WITH OTHER THIRD-PARTY SOFTWARE BEYOND THE THIRD- PARTY SOFTWARE EXPRESSLY APPROVED AS COMPLIANT IN THE DOCUMENTATION. EXCEPT AS TO COMPATIBILITY OF THE LICENSED SOFTWARE AS DESCRIBED IN AVEPOINT’S DOCUMENTATION, AVEPOINT MAKES NO WARRANTIES TO CUSTOMER WITH RESPECT TO CUSTOMER'S COMPUTER EQUIPMENT OR SYSTEM SOFTWARE OR ITS CAPACITY. FURTHERMORE, AVEPOINT DOES NOT WARRANT THAT ANY SOFTWARE ERRORS, DEFECTS, OR INEFFICIENCIES WILL BE CORRECTED, NOR DOES AVEPOINT ASSUME ANY LIABILITY FOR FAILURE TO CORRECT ANY SUCH ERROR, DEFECT OR INEFFICIENCY. AVEPOINT MAKES NO WARRANTY, AND CUSTOMER ASSUMES THE ENTIRE RISK, AS TO THE INTEGRITY OF ANY DATA AND THE RESULTS, CAPABILITIES, SUITABILITY, USE, NON-USE OR PERFORMANCE OF THE SOLUTIONS. IN NO EVENT SHALL AVEPOINT BE LIABLE TO CUSTOMER FOR ANY DAMAGES RESULTING FROM OR RELATED TO THE USE OF THE SOLUTIONS. CUSTOMER MAY HAVE OTHER STATUTORY RIGHTS, BUT THE DURATION OF STATUTORILY REQUIRED WARRANTIES, IF ANY, SHALL BE LIMITED TO THE SHORTEST PERIOD PERMITTED BY LAW.

  • Review of legality and data minimisation (a) The data importer agrees to review the legality of the request for disclosure, in particular whether it remains within the powers granted to the requesting public authority, and to challenge the request if, after careful assessment, it concludes that there are reasonable grounds to consider that the request is unlawful under the laws of the country of destination, applicable obligations under international law and principles of international comity. The data importer shall, under the same conditions, pursue possibilities of appeal. When challenging a request, the data importer shall seek interim measures with a view to suspending the effects of the request until the competent judicial authority has decided on its merits. It shall not disclose the personal data requested until required to do so under the applicable procedural rules. These requirements are without prejudice to the obligations of the data importer under Clause 14(e). (b) The data importer agrees to document its legal assessment and any challenge to the request for disclosure and, to the extent permissible under the laws of the country of destination, make the documentation available to the data exporter. It shall also make it available to the competent supervisory authority on request.

  • WARRANTY TERMS The Seller shall provide warranty for the quality of the Equipment for a period of 12 months. The warranty term shall commence on the day following the date of signing of the Handover Protocol pursuant to Section 10.4 hereof. In case the Buyer accepted the Equipment with defects or unfinished work the warranty term shall commence on the day following the date of removal of the defects or unfinished work. The warranty does not cover consumable things.

  • Construction Warranty At the Closing, Seller shall assign to Buyer all construction warranties with respect to the Hotel, which assignment shall be in form and substance reasonably satisfactory to Buyer, including a warranty by the Contractor, for the period ending not sooner than one (1) year after the date the Hotel is Substantially Completed, in the form of the warranty attached hereto as Exhibit H (the “Construction Warranty”).

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • NO STRIKE CLAUSE During the life of this Agreement the VSEA and employees covered by this Agreement acknowledge their statutory obligations in relation to 3 VSA 903(b) and agree to be bound thereby.

  • Warranty Disclaimers WE ARE LEASING THE EQUIPMENT TO YOU “AS-IS.” YOU HAVE SELECTED SUPPLIER AND THE EQUIPMENT BASED UPON YOUR OWN JUDGMENT. IN THE EVENT WE ASSIGN THIS AGREEMENT, OUR ASSIGNEE DOES NOT TAKE RESPONSIBILITIES FOR THE INSTALLATION OR PERFORMANCE OF THE EQUIPMENT. SUPPLIER IS NOT AN AGENT OF OURS AND WE ARE NOT AN AGENT OF SUPPLIER, AND NOTHING SUPPLIER STATES OR DOES CAN AFFECT YOUR OBLIGATIONS HEREUNDER. YOU WILL MAKE ALL PAYMENTS UNDER THIS AGREEMENT REGARDLESS OF ANY CLAIM OR COMPLAINT AGAINST ANY SUPPLIER, LICENSOR OR MANUFACTURER, AND ANY FAILURE OF A SERVICE PROVIDER TO PROVIDE SERVICES WILL NOT EXCUSE YOUR OBLIGATIONS TO US UNDER THIS AGREEMENT. WE MAKE NO WARRANTIES, EXPRESS OR IMPLIED, OF, AND TAKE ABSOLUTELY NO RESPONSIBILITY FOR, MERCHANTABILITY, FITNESS FOR ANY PARTICULAR PURPOSE, CONDITION, QUALITY, ADEQUACY, TITLE, DATA ACCURACY, SYSTEM INTEGRATION, FUNCTION, DEFECTS, INFRINGEMENT OR ANY OTHER ISSUE IN REGARD TO THE EQUIPMENT, ANY ASSOCIATED SOFTWARE AND ANY FINANCED ITEMS. SO LONG AS YOU ARE NOT IN DEFAULT UNDER THIS AGREEMENT, WE ASSIGN TO YOU ANY WARRANTIES IN THE EQUIPMENT GIVEN TO US.

  • Contractor Representations Contractor represents and warrants to Subcontractor as follows: (a) Contractor (i) is duly organized, validly existing and in good standing under the laws of its state of incorporation or organization, (ii) has the power and authority to own its properties and to carry on business as now being conducted, and (iii) has the power to execute and deliver this Subcontract; (b) The execution and performance by Contractor of the terms and provisions of this Subcontract by Contractor have been duly authorized by all requisite action, and neither the execution nor the performance of this Subcontract will violate any provision of law, any order of any court or other agency of government, the organizational documents of Contractor or any indenture, agreement or other instrument to which Contractor is a party, or by which Contractor is bound, or be in conflict with, result in a breach of, or constitute (with due notice or lapse of time or both) a default under, or except as may be provided by this Subcontract, result in the creation or imposition of any lien, charge or encumbrance of any nature whatsoever upon any of the property or assets of Contractor pursuant to, any such indenture agreement or instrument; (c) Contractor has obtained all licenses, permits and approvals required to perform the Services to be provided by Contractor under the Prime Contract; and (d) Contractor is not under suspension or debarment by the Commonwealth or any other governmental entity, instrumentality or authority.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!