Weather Condition. In the event of unfavourable weather on the date specified for the trial run, the trial run shall take place on the first available day that weather conditions permit. The parties hereto recognise that the weather conditions in Korean waters, in which the trial run is to take place, are such that great changes in weather may arise momentarily and without warning and therefore, it is agreed that if, during the trial run, the weather should become so unfavourable that the trial run cannot be continued, then the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent to the acceptance of the VESSEL by notification in writing on the basis of such trial run so far made prior to such change in weather conditions. Any delay of the trial run caused by weather conditions in excess of Beaufort 5 shall also operate to extend the DELIVERY DATE of the VESSEL for the period of delay occasioned by such unfavourable weather conditions.
Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable enough by the judgement of the BUILDER. In the event of unfavourable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSEL.
Weather Condition. The trial run shall be carried out under the weather condition which is deemed favorable enough in the reasonable judgment of the SELLER. In the event of unfavourable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the speed trial of the VESSEL, the weather is unfavourable (i.e. sea state of 3 and wind state of Beaufort 3 or worse) that orderly conduct of the speed trial can no longer be continued, the speed trial shall be discontinued and postponed until the first favorable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the speed trial already made before such discontinuance has occurred. Any delay of the trial run caused by such unfavourable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as Permissible Delay in the delivery of the VESSEL.
Weather Condition. The sea trial and any other tests and trials of the DRILLSHIP as per the Specifications shall be carried out under the weather condition that is deemed favorable enough by the judgment of both the BUYER and the BUILDER and as per the Specifications. In the event of unfavorable weather on the date specified for the sea trial or other tests and trials as per the Specifications, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the sea trial or other tests and trials of the DRILLSHIP as per the Specifications, the weather should suddenly become so unfavorable that orderly conduct of the test or trial can no longer be continued, the test or trial shall be discontinued and postponed until the first favorable day next following, unless the BUYER shall assent in writing to acceptance of the DRILLSHIP on the basis of the tests and trials already made before such discontinuance has occurred. Any delay of sea trial caused by such unfavorable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the DRILLSHIP.
Weather Condition. The trial run shall be carried out under weather conditions deemed sufficiently favourable by the BUILDER, and as further described in the Specifications. Any delay of delivery caused by delayed trial run due to unfavourable weather conditions shall be considered Permissible Delay.
Weather Condition. In the event of unfavorable weather on the date specified for the trial run, the trial run shall take place on the first available day that weather conditions permit. The parties hereto recognize that the weather conditions in Korean waters, in which the trial run is to take place, are such that great changes in weather may arise momentarily and without warning and therefore, it is agreed that if, during the trial runs, the weather should become so unfavorable that the trial run cannot be continued, then the trial run shall be discontinued and postponed until the first favorable day next following, unless the BUYER shall assent to the acceptance of the VESSEL by notification in writing on the basis of such trial run so far made prior to such change in weather conditions. Any delay of the trial run caused by such unfavorable weather conditions shall also operate to extend the DELIVERY DATE of the VESSEL for the period of delay occasioned by such unfavorable weather conditions.
Weather Condition. The trial run shall be carried out under weather conditions deemed favorable enough in the judgment of the BUILDER. In the event of unfavorable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavorable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favorable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavorable weather condition shall operate to postpone the Delivery Date by the period of delay involved and such delay shall be deemed as a permissible delay in the delivery of the VESSEL.
Weather Condition. The sea trial shall be carried out under such weather condition as the Builder in his reasonable judgment has deemed favourable. In the event of unfavourable weather on the date specified for the sea trial, the same shall take place on the first available day thereafter that the weather permits. It is agreed that if during the sea trial of the Vessel the weather should suddenly become unfavourable to continue the sea trial, the sea trial shall be discontinued and postponed until the first favourable day next following, unless the Buyer shall assent in writing to its acceptance of the Vessel on the basis of the sea trial made before such discontinuance has occurred. Any delay of the sea trial caused by such unfavourable weather condition shall operate to postpone the Expected Delivery Date by the period of delay involved and such delay shall be deemed to be a permissible delay in delivery of the Vessel.
Weather Condition. In the event of unfavourable weather on the date specified for the trial run, the trial run shall take place on the first available day that weather conditions permit. The parties hereto recognize that the weather conditions in Philippines waters, in which the trial run is to take place, are such that great changes in weather may arise momentarily and without warning and therefore, it is agreed that if, during the trial run, the weather should become so unfavourable that the trial run cannot be continued, then the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent to the acceptance of the VESSEL by notification in writing on the basis of such trial run so far made prior to such change in weather conditions. Any reasonable delay of the trial run caused by such unfavourable weather conditions shall also operate to extend the Delivery Date of the VESSEL for the period of delay occasioned by such unfavourable weather conditions.
Weather Condition. (1) Employees shall not be required to do any unreasonable work in the open (outside) during inclement weather, but the employee's) must carry out assignment(s) given to them during an emergency.
(2) The City is sensitive to employees working in temperature extremes. The Director of Public Works or their designee at their discretion, shall make reasonable efforts when the temperature is zero (0) degrees Fahrenheit or lower of ninety (90) degrees Fahrenheit or higher, to ensure employees will not be required to perform outside duties outside of the normal practice except in emergency situations.
