Where a Notice Sample Clauses

The 'Where a Notice' clause defines the circumstances and procedures under which formal notifications between parties must be given within a contract. Typically, it specifies the required method of delivery (such as email, registered mail, or personal delivery), the address to which notices should be sent, and when a notice is considered effectively received. This clause ensures that all parties have a clear and agreed-upon process for communicating important information, thereby reducing the risk of misunderstandings or disputes regarding whether and when a notice was properly given.
Where a Notice of Dis satisfaction has been given, both Parties shall attempt to settle the dispute amicably before the commencement of arbitration. However, unless both Parties agree otherwise, the Party giving a Notice of Dissatisfaction in accordance with Sub-Clause 8.1 above should move to commence arbitration after the fifty-sixth day from the day on which a Notice of Dissatisfaction was given, even if no attempt at an amicable settlement has been made.
View SourceView Similar (8)

Related to Where a Notice

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and

  • Notice of Material Events The Borrower will notify the Administrative Agent, for distribution to the LC Issuer and each Lender, promptly, and not later than five (5) Business Days in the case of subsection (b) below and not later than ten (10) Business Days in the case of any other subsection below, after any Responsible Officer or general counsel of the Borrower has knowledge thereof, stating that such notice is being given pursuant to this Agreement, of: (a) the occurrence of any event or circumstance that has had, or could reasonably be expected to have, a Material Adverse Effect, (b) the occurrence of any Default, (c) the acceleration of the maturity of any Indebtedness owed by the Borrower or any of its Subsidiaries or of any default by the Borrower or any of its Subsidiaries under any Contractual Obligation of the Borrower or such Subsidiary, if such acceleration or default has had or could reasonably be expected to have a Material Adverse Effect, (d) the occurrence of any Termination Event, (e) the filing of any suit or proceeding, or the assertion in writing of a claim against the Borrower or any Material Subsidiary or with respect to the Borrower’s or any Material Subsidiary’s properties which could reasonably be expected to result in liability to Borrower or such Material Subsidiary in excess of $50,000,000; (f) the occurrence of any event of default by the Borrower or any of its Subsidiaries in the payment or performance of (i) any material obligations such Person is required to pay or perform under the terms of any indenture, mortgage, deed of trust, security agreement, lease, and franchise, or other agreement, contract or other instrument or obligation to which it is a party or by which it or any of its properties is bound, or (ii) any Indebtedness, to the extent, in the case of clauses (i) and (ii), such event of default could reasonably be expected to have a Material Adverse Effect; and (g) any announcement of any change in a Rating. Each notice pursuant to this Section shall be accompanied by a statement of a Responsible Officer of the Borrower setting forth details of the occurrence referred to herein and stating what action the Borrower, Subsidiary or Material Subsidiary, as applicable, has taken and proposes to take with respect thereto. Each notice pursuant to Section 6.03(b) shall describe with particularity any all provisions of this Agreement and if, applicable, other Loan Documents, that have been breached.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.