ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Client Agreement We are not required to enter into a written agreement complying with the Code relating to the services that are to be provided to you.
FRAMEWORK AGREEMENT MANAGEMENT The Parties shall manage this Framework Agreement in accordance with Schedule 14 (Framework Management).
Framework Agreement 4.1.2.1 The Parties shall enter into a Framework Agreement within 28 days after the Contractor receives the Letter of Acceptance, unless the Particular Conditions establish otherwise. The Framework Agreement shall be based upon FORM No. 3 – FRAMEWORK AGREEMENT annexed to the Particular Conditions. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Framework Agreement shall be borne by the Procuring Entity.
4.1.2.2 The Framework Agreement establishes the terms and conditions that will govern the contract awarded during the term of the Framework Agreement. The Framework Agreement establishes for the procurement works by package as and when required, over the specified period of time. The Framework Agreement does not commit a Procuring Entity to procure, nor a Firm to supply. The Framework Agreement allows the Procuring Entity to call the Contractor to commence the works on a particular package in a specified location within the duration of the agreement.
4.1.2.3 This Framework Agreement does not guarantee the contractor of being called for a contract to start and no commitment is made with regard to possible number of packages to carry out.
4.1.2.4 This Framework Agreement does exclude the Procuring Entity from the right to procure the same Works from other firms.
4.1.2.5 This Framework Agreement does not stop the Procuring Entity from removing the contractor from the same Agreement.
4.1.2.6 FAs shall be established for a maximum period of three (3) years. The Procuring Entity may with the Consent of the Contractor extend this Agreement if the agreement period is less than three (3) years, if the initial engagement has been satisfactory.
4.1.2.7 Call-off Contracts; for work on a package to start, the Procuring Entity shall issue a notice of acceptance of a particular package requesting the contractor to furnish a Performance Security and to start the works thereafter, and providing the contractor with details of location where the works, are to be carried out. The call-off statement shall specify the objectives, tasks, deliverables, timeframes and price or price mechanism. The price for individual call-off contracts shall be based on the prices detailed in the Framework Agreement.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Independent Agreement Notwithstanding any other provision of this Agreement, including the recitals hereof, the parties agree that the Lease Agreement executed between the parties thereto shall be a separate and independent document from this Agreement, and irrespective of whether any provision of this Agreement or the entirety hereof shall be held invalid or unenforceable by any court of competent jurisdiction, the Lease Agreement shall be construed, interpreted, and otherwise regarded separate and apart from this Agreement. The parties hereto specifically note that the considerations and terms provided for in this Agreement and provided for in the Lease Agreement are the only considerations and terms for which the parties thereto have executed this Agreement.
Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.
AGREEMENT RE-OPENER This Agreement may be amended by mutual consent. If either party wishes to amend or vary this Agreement, it shall give to the other party notice of any amendment proposed and the parties shall meet and discuss such proposal not later than one (1) calendar month after receipt of such notice.
Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.
Side Letter The letter from the Borrower to the Agent dated July 17, 2000 that was executed in connection with the Second Amendment shall remain in full force and effect and shall be a Loan Document.
