STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby.
13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition.
13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and
13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph
13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State.
13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal.
13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the
Notice of Network Changes If a Party makes a change in the information necessary for the transmission and routing of services using that Party’s facilities or network, or any other change in its facilities or network that will materially affect the interoperability of its facilities or network with the other Party’s facilities or network, the Party making the change shall publish notice of the change at least ninety (90) days in advance of such change, and shall use reasonable efforts, as commercially practicable, to publish such notice at least one hundred eighty (180) days in advance of the change; provided, however, that if an earlier publication of notice of a change is required by Applicable Law (including, but not limited to, 47 CFR 51.325 through 51. 335) notice shall be given at the time required by Applicable Law.
Notice to Borrower The Agent shall promptly notify the Borrower of the terms (x) of any Money Market Quote submitted by a Bank that is in accordance with subsection (d) and (y) of any Money Market Quote that amends, modifies or is otherwise inconsistent with a previous Money Market Quote submitted by such Bank with respect to the same Money Market Quote Request. Any such subsequent Money Market Quote shall be disregarded by the Agent unless such subsequent Money Market Quote is submitted solely to correct a manifest error in such former Money Market Quote. The Agent's notice to the Borrower shall specify (A) the aggregate principal amount of Money Market Loans for which offers have been received for each Interest Period specified in the related Money Market Quote Request, (B) the respective principal amounts and Money Market Margins or Money Market Absolute Rates, as the case may be, so offered and (C) if applicable, limitations on the aggregate principal amount of Money Market Loans for which offers in any single Money Market Quote may be accepted.
Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.
Notice of Work Schedules
(a) Work schedules for regular employees shall be posted at least 14 days in advance of the starting day of a new schedule.
(b) In the event that the work schedule or shift for a regular employee or an auxiliary employee working a scheduled shift roster is changed without 48 hours' advance notice and such change is the result of the actions of another employee covered by this agreement utilizing the benefits provided for by the provisions of this agreement, the employee will receive a premium of 85¢ per hour in addition to their regular pay, for work performed on the first shift to which they changed.
(c) In the event that an employee's work schedule or shift is changed without five days advance notice and the change results from causes other than defined in (b) above, the employee shall receive a premium at the applicable overtime rate for work performed on the first shift to which they changed, except that if the change results from no fault of the Employer they shall not receive a premium at overtime rates but shall receive the premium defined under (b) above.
Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.
Advance Notice of Layoff Unless legislation is more favourable to the Employees, the Employer shall notify Employees who are laid off with a written notice thirty (30) calendar days prior to the effective date of layoff. If the Employee has not had the opportunity to work the days as provided in this Article, they shall be paid for the days for which work was not made available.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
