Procurement Planning Prior to the issuance of any invitations to bid for contracts, the proposed procurement plan for the Project shall be furnished to the Association for its review and approval, in accordance with the provisions of paragraph 1 of Appendix 1 to the Guidelines. Procurement of all goods and works shall be undertaken in accordance with such procurement plan as shall have been approved by the Association, and with the provisions of said paragraph 1.
Business Continuity Planning Supplier shall prepare and maintain at no additional cost to Buyer a Business Continuity Plan (“BCP”). Upon written request of Buyer, Supplier shall provide a copy of Supplier’s BCP. The BCP shall be designed to ensure that Supplier can continue to provide the goods and/or services in accordance with this Order in the event of a disaster or other BCP-triggering event (as such events are defined in the applicable BCP). Supplier’s BCP shall, at a minimum, provide for: (a) the retention and retrieval of data and files; (b) obtaining resources necessary for recovery, (c) appropriate continuity plans to maintain adequate levels of staffing required to provide the goods and services during a disruptive event; (d) procedures to activate an immediate, orderly response to emergency situations; (e) procedures to address potential disruptions to Supplier’s supply chain; (f) a defined escalation process for notification of Buyer, within two (2) business days, in the event of a BCP-triggering event; and (g) training for key Supplier Personnel who are responsible for monitoring and maintaining Supplier’s continuity plans and records. Supplier shall maintain the BCP and test it at least annually or whenever there are material changes in Supplier’s operations, risks or business practices. Upon Xxxxx’s written and reasonable request, Supplier shall provide Buyer an executive summary of test results and a report of corrective actions (including the timing for implementation) to be taken to remedy any deficiencies identified by such testing. Upon Xxxxx’s request and with reasonable advance notice and conducted in such a manner as not to unduly interfere with Supplier’s operations, Supplier shall give Buyer and its designated agents access to Supplier’s designated representative(s) with detailed functional knowledge of Supplier’s BCP and relevant subject matter.
Project Management Plan 3.2.1 Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan, Good Industry Practice and applicable Law. 3.2.2 Developer shall develop the Project Management Plan and its component parts, plans and other documentation in accordance with the requirements set forth in Section 1.5.2.5
Virus Management DST shall maintain a malware protection program designed to deter malware infections, detect the presence of malware within DST environment.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
Patch Management All workstations, laptops and other systems that process and/or 20 store PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or 21 transmits on behalf of COUNTY must have critical security patches applied, with system reboot if 22 necessary. There must be a documented patch management process which determines installation 23 timeframe based on risk assessment and vendor recommendations. At a maximum, all applicable 24 patches must be installed within thirty (30) calendar or business days of vendor release. Applications 25 and systems that cannot be patched due to operational reasons must have compensatory controls 26 implemented to minimize risk, where possible.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Flextime (a) For the purpose of this agreement, flextime means the hours worked by an employee, or group of employees, who are given authority by the Employer to: (1) choose their starting and finishing times; and (2) choose their length of workday within a stated maximum number of hours, subject to meeting the required annual hours of work in accordance with this agreement, through a specified averaging period. (b) The full-time employee on flextime who has a day of absence, whether with or without pay, will be deemed to be absent for the agreed upon hours, providing at least the agreed upon hours are required to complete the averaging period. If less than the agreed upon hours are required to complete the averaging period, such number of hours will be deemed to be the hours of absence. (c) The averaging period for employees on flextime will be two pay periods. (d) The workday for those employees on flextime will not exceed 10 hours.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System. 4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System. 4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA. 4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code. 4.1.5 The Power Producer shall commission the Project within SCOD. 4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer. 4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.
