Acceleration Schedule definition

Acceleration Schedule has the meaning set forth in Section 5.6A.
Sample 1Sample 2Sample 3

Examples of Acceleration Schedule in a sentence

  • The revised Acceleration Schedule shall then be the schedule which Contractor shall use in planning, organizing, directing, coordinating, performing, and executing that portion of the Work that is affected by such acceleration, with the CPM Schedule governing the performance of all other Work.

  • The Acceleration Schedule shall be prepared using GECP and to a similar level of detail as the CPM Schedule.

  • Owner’s review of the Acceleration Schedule shall not constitute an independent evaluation or determination by Owner of the workability, feasibility, or reasonableness of that schedule.

  • The Acceleration Schedule shall represent Contractor’s best judgment as to how it shall satisfy the Confirmed Acceleration Directive.

  • On the tenth (10th) Business Day after execution of the Change Order with respect to the Confirmed Acceleration Directive (or such longer time as specified in writing by Owner), Contractor shall participate in a conference with Owner, and with any other Person (including Subcontractors and Sub-subcontractors) whom Owner reasonably designates to participate, to review and evaluate the Acceleration Schedule.

  • Any revisions to the Acceleration Schedule necessary as a result of this review shall be resubmitted for review by Owner as soon as reasonably practicable or as mutually agreed by the Parties.

  • No later than the tenth (10th) Business Day after execution of the Change Order with respect to the Confirmed Acceleration Directive, Contractor shall prepare the Acceleration Schedule and submit it to Owner for its review.

  • All submittals by Contractor to Owner of the CPM Schedule, Recovery Schedule, Acceleration Schedule and any Monthly Updated CPM Schedule shall be in both hard copy and native electronic Primavera Project Planner format.

  • Owner’s review and approval of the Acceleration Schedule shall not constitute an independent evaluation or determination by Owner of the workability, feasibility, or reasonableness of that schedule.

  • Any revisions to the Acceleration Schedule necessary as a result of this review shall be resubmitted for review by Owner as soon as reasonably practicable.

Related to Acceleration Schedule

  • Amortization Schedule means, with respect to each Equipment Note, the amortization schedule for such Equipment Note delivered pursuant to Section 2.02 of the Trust Indenture.

  • Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.

  • Conversion Schedule means the Conversion Schedule in the form of Schedule 1 attached hereto.

  • Repayment Schedule means the schedule of repayment dates as detailed in Schedule 5 (Loan Repayment Schedule), to be replaced as required in accordance with Clause 5 (Repayment) and Clause 6.10(b) (Partial prepayment of Loans).

  • Early Termination Schedule is defined in Section 4.2 of this Agreement.

  • Acceleration Notice shall have the meaning specified in Section 6.2.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Expected Amortization Schedule means, with respect to any Tranche, the expected amortization schedule related thereto set forth in the Series Supplement.

  • Delegation Schedule means any separate schedule entered into between the Custodian and the Fund or its authorized representative with respect to certain matters concerning the appointment and administration of Subcustodians delegated to the Custodian pursuant to Rule 17f-5 under the 1940 Act.

  • Specification Schedule means the Schedule containing details of the Specification.

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Allocation Schedule has the meaning set forth in Section 2.07.

  • Payment Schedule ’ means a schedule which sets out—

  • Purchase Price Allocation Schedule has the meaning given to it in Section 2.7(a).

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Shift Schedule means a written statement setting forth the days and hours upon which the employees are required to work.

  • Acceleration Date on any Security means the date, if any, on and after which the principal or any or all installments of interest, or both, are due and payable on any Security which has become accelerated pursuant to the terms of the Security.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Contract Schedule The list (as such list may be amended from time to time) identifying each Contract constituting part of the corpus of the Trust Fund as of the Cut-off Date, and which (a) identifies each Contract as either a Fixed Rate Contract or Adjustable Rate Contract and by contract number and name and address of the Obligor and (b) sets forth as to each Contract (i) the unpaid principal balance as of the related Transfer Date determined by giving effect to payments received prior to the related Transfer Date, (ii) the amount of each scheduled payment due from the Obligor, and (iii) the APR.

  • Country Limitation Schedule means the schedule published from time to time by Ex-Im Bank setting forth on a country by country basis whether and under what conditions Ex-Im Bank will provide coverage for the financing of export transactions to countries listed therein.

  • Acceleration Event means the occurrence of an Event of Default (a) in respect of which Agent has declared all or any portion of the Obligations to be immediately due and payable pursuant to Section 10.2, (b) pursuant to Section 10.1(a), and in respect of which Agent has suspended or terminated the Revolving Loan Commitment pursuant to Section 10.2, and/or (c) pursuant to either Section 10.1(e) and/or Section 10.1(f).

  • Pricing Schedule means the Schedule attached hereto identified as such.

  • Acceleration as defined in Subsection 9.1(e).

  • Asset Schedule means with respect to any Transaction as of any date, an asset schedule in the form of a computer tape or other electronic medium (including an Excel spreadsheet) generated by Seller and delivered to Buyer and the Custodian, which provides information (including, without limitation, the information set forth on Exhibit E attached hereto) relating to the Purchased Mortgage Loans in a format reasonably acceptable to Buyer.

  • Schedule means a schedule to this Agreement.

  • Time Schedule means the Time Schedule for final completion of the Works or Mechanical Completion of the Plant(s)/Unit(s), as the case may be, incorporated in the Contract or as may be extended by the OWNER or Engineer- in-Charge pursuant to the provisions hereof and shall include interim time schedules set up for achieving interim/phase-wise/stage-wise progress/completion/testing/commissioning/ handing over, as may be prescribed by the OWNER/Engineer-in-Charge, within the overall Time Schedule as originally envisaged or as extended.