Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.
Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.
Unilateral Change Order (ULCO means a Change Order issued by Owner without the complete agreement of Contractor, as to cost and/or time.
Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:
Purchase Order (PO) means a written offer made by a purchaser to a supplier formally stating the terms and conditions of a proposed transaction.
Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Delivery Schedule means the schedule for the delivery of Services as set forth in attached Annex 3.
Purchase Order Number means the Customer’s unique number relating to the supply of the Services;
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Contract Schedule The list (as such list may be amended from time to time) identifying each Contract constituting part of the corpus of the Trust Fund as of the Cut-off Date, and which (a) identifies each Contract as either a Fixed Rate Contract or Adjustable Rate Contract and by contract number and name and address of the Obligor and (b) sets forth as to each Contract (i) the unpaid principal balance as of the related Transfer Date determined by giving effect to payments received prior to the related Transfer Date, (ii) the amount of each scheduled payment due from the Obligor, and (iii) the APR.
Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.
Specification Schedule means the Schedule containing details of the Specification.
Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;
Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
The Work Order means the order placed by the Purchaser on the Supplier signed by the Purchaser including all attachments and appendices thereto and all documents incorporated by reference therein. The Work order shall be deemed as "Contract" appearing in the document.
Original contract price means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.
Product Schedule means the “Product Schedule” that forms part of the Contract.
Schedule of Work means that schedule attached to the Interconnection Construction Service Agreement setting forth the timing of work to be performed by the Constructing Entity pursuant to the Interconnection Construction Service Agreement, based upon the Facilities Study and subject to modification, as required, in accordance with Transmission Provider’s scope change process for interconnection projects set forth in the PJM Manuals.
Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.
Template Order Form means the template form in Annex 1 to Framework Schedule 4 (Template Order Form and Template Call Off terms);
Service Order Form means our standard Service Order Form for Services, or any other order form that we agree with you in writing that incorporates the provisions of this DPA;
Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.
IITK Purchase Order means the IITK’s official Purchase Order document;