Commissioning Completion Date definition

Commissioning Completion Date the date of handover of the Gas Consuming Plant to the Operator pursuant to the contract for the construction of the Gas Consuming Plant;
Sample 1Sample 2
Commissioning Completion Date has the meaning set forth in the Wind Turbine Supply Agreement.
Sample 1Sample 2
Commissioning Completion Date means the earlier of (i) the date on which Commissioning Completion occurs or is deemed to have occurred for a Wind Turbine or (ii) the date on which Supplier submits a Delayed Commissioning Completion Certificate to Buyer for a Wind Turbine in accordance with Section 4.2.4.
Sample 1Sample 2

Examples of Commissioning Completion Date in a sentence

  • From the Commissioning Completion Date for the first Wind Turbine and through the end of the Term, Supplier shall maintain or cause to be maintained Excess Liability Insurance of not less than Five Million Dollars (U.S. $5,000,000).

  • From the Commissioning Completion Date for the first Wind Turbine and through the end of the Term, Buyer shall maintain or cause to be maintained Excess Liability Insurance of not less than Five Million Dollars (U.S. $5,000,000).

  • From the Commissioning Completion Date for the first Wind Turbine and through the end of the Term, Buyer shall maintain or cause to be maintained All Risk Property Insurance (including earth movement and flood, collapse, sinkhole and subsidence) on a completed value form.

  • Concurrently with the Project Substantial Completion, all WTG Commissioning Delay Liquidated Damages shall be due and payable and payment of such liquidated damages shall constitute the sole liability of Seller and the exclusive remedy of the Owner for Seller's failure to meet the Guaranteed WTG Commissioning Completion Date.

  • In the event of occurrence of suspension of the Wind Turbine Work by Seller pursuant to Section 6.2, Seller shall be entitled to a Change Order reflecting the result and impact of such suspension on the Wind Turbine Work, including, but not limited to, Contract Price, the Delivery Schedule, the Warranty and the Guaranteed WTG Commissioning Completion Date.

  • During the period from the Commencement Date for the first Wind Turbine until the Final Commissioning Completion Date, Buyer shall pay Supplier a fee equal to One Hundred Fifty-Seven Dollars ($157) per day per Wind Turbine that has achieved Commissioning Completion during such period (the “Interim Service Fee”).

  • Seller shall complete Commissioning of each WTG no later than its respective Guaranteed WTG Commissioning Completion Date.

  • If Commissioning of WTGs is not achieved by the Guaranteed WTG Commissioning Completion Date calculated by the sum of the actual completion days for Commissioning of all WTGs divided by the number of WTGs with the consideration of Excusable Delay applicable herein, Seller shall pay as liquidated damages to Buyer an amount equal to *** US Dollars (US $***) per WTG ("WTG Commissioning Delay Liquidated Damages") for each day multiplied by the number of WTGs.

  • Although EGAT shall by Law and the provisions of Section 2.6 and this Section 2.8.1 have legal title to the New Transmission Facilities from the start of their construction, the Generator shall bear the risk of loss of or damage to the New Transmission Facilities until the NTF Commissioning Completion Date.

  • On and after the date that is nine (9) months after the Commissioning Completion Date of the last Nominated Wind Turbine, Buyer shall no longer have the right to request a verification of the Power Curve.


More Definitions of Commissioning Completion Date

Commissioning Completion Date means the date upon which Bulk Terminal Dock 3 is verified (by testing and inspecting) and documented that the operational components were installed and are operating in accordance the design.
Sample 1
Commissioning Completion Date means the date on which DOE has confirmed in writing to the Borrower that Commissioning Completion has occurred.
Sample 1

Related to Commissioning Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Commissioning means the process for determining the need for and for obtaining the supply of healthcare and related services by the Trust within available resources.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which: