Completion of Facilities definition

Completion of Facilities means that all the Facilities (or a specific part thereof where specific parts are specified in the SCC) have been completed operationally and structurally as per Technical Specifications and put in a tight and clean condition and that all work in respect of Precommissioning of the Facilities or such specific part thereof has been completed and Commissioning has been attained as per Technical specifications.
Sample 1Sample 2Sample 3
Completion of Facilities means the term ‘Completion of Facilities ’ as defined in the Contract.
Sample 1Sample 2Sample 3
Completion of Facilities means that the Facilities (or a specific part thereof where specific parts are specified in the SCC) have been completed operationally and structurally and put in a tight and clean SECI/SD/2/NIT/2016/KPL Section IV: GCC Page 4 of 47Signature of Bidder condition, and that all work in respect of Pre-commissioning of the Facilities or such specific part thereof has been completed; and Installation, Testing & Commissioning has been completed for all individual components of the Infrastructure as per Technical Specifications.
Sample 1

Examples of Completion of Facilities in a sentence

  • Effective Date for Determining Time for Completion3.1 Effective Date (Reference GCC Clause 1) The Time of Completion of Facilities shall be determined from the date of the Notification of Award i.e., from………………… Article 4.

  • The aforesaid retained amount shall be paid along with payment due on completion of Trial Operation / Completion of Facilities.

  • The procedure tends to be a matter of local protocol at Councils and has not tended to be subject to scrutiny.

  • Time for CompletionThe Time of Completion of Facilities shall be determined in Months from the date of the Letter of Award (LoA) i.e., w.e.f. XX.XX.XXXX.

  • Effective Date for Determining Time for Completion 3.1 Effective Date (Reference GCC Clause 1) The Time of Completion of Facilities shall be determined from the date of the Notification of Award i.e., from ………………… Article 4.

  • If the successful Completion of Facilities is not attained within 18 months from the date of Notification of Award by NLCIL on BHEL, for reasons attributable to Associate, then the Liquidated Damages payable at the rate of 0.5% per week of delay or part thereof of supply and services subject to a ceiling of 10% of the total value of contract for supply & services, shall be payable by Associate on whom BHEL has placed order for BESS.17.

  • It will be the responsibility of the Contractor to provide all commissioning spares including consumable spares required for initial operation till the Completion of Facilities.

  • The Construction Completion Schedule with associated construction values for each benchmark shall set forth completion dates for the following benchmarks as needed: i) Completion of Excavation; ii) Completion of Electrical; iii) Completion of Mechanical; iv) Completion of Facilities; v) Completion of Hardscaping and Landscaping; and any further construction benchmarks and conditions as may be determined by the Director of Public Works.

  • On 16.03.2016, PCTEL completed facilities Cooling Tower No. 3 (CT#3), Cooling Tower No. 4 (CT#4) and Control Room under Clause 24 of the General Conditions of Contract (GCC) (Commissioning and Completion of Facilities).

  • On 21.04.2016, PCTEL informed KBUNL that it had completed the works under Clause 24 of the GCC and requested issuance of a certificate of Completion of Facilities (‘COF’) and release of its dues.


More Definitions of Completion of Facilities

Completion of Facilities means that all the Facilities (or a specific part
Sample 1Sample 2
Completion of Facilities means that all the Facilities (or a specific part thereof where specific parts are specified in the SCC) have been completed operationally and structurally as per Technical Specifications and put in a tight and clean condition and that all work in respect of Pre-
Sample 1Sample 2
Completion of Facilities means that the Facilities (or a specific part thereof where specific parts are specified in the SCC) have been completed operationally and structurally and put in a tight and clean DEVELOPMENT OF 50 MW (AC) SOLAR PV PROJECT GENERAL CONDITIONS OF CONTRACT. – SECI/C&P/PMC/NIT/2016/THDCIL/50 Page 4 of 48 Signature of Bidder condition, and that all work in respect of Pre-commissioning of the Facilities or such specific part thereof has been completed; and Commissioning has been attained as per Technical Specifications.
Sample 1Sample 2
Completion of Facilities means that the Facilities (or a specific part thereof where specific parts are
Sample 1Sample 2
Completion of Facilities means that the Facilities (or a specific part thereof where specific parts are specified in the SCC) have been completed operationally and structurally and put in a tight and clean condition, and that all work in respect of Pre-commissioning of the Facilities or such NIT for Procurement of Land, Design, Engineering, Supply, Construction, Erection, Testing, Commissioning and O&M of 100MW (DCR) (AC) Solar PV power plant-Package-A and Procurement of Land, Design, Engineering, Supply, Construction, Erection, Testing, Commissioning and O&M of 100MW (DCR) (AC) Solar PV power plant-Package-B, in the state of Madhya Pradesh for CIL.. specific part thereof has been completed; and Commissioning has been attained as per Technical Specifications.
Sample 1

Related to Completion of Facilities

  • Project Facilities means all the amenities and facilities situated on the Site, as described in Schedule-C;

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • construction site means a workplace where construction work is being performed;

  • Construction Work means any work in connection with⎯

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • New Facilities means facilities for which, by the cut-off date, neither of the following events has occurred:

  • Project Facility means facility being one or more of the following facilities as specified in the Special Conditions of Contract, being developed in accordance with the Project and the Detailed Project Implementation Report and includes all its buildings, equipment, facilities, software and systems and includes without limitation, where the circumstances so require, any expansion thereof from time to time and may include any new location to be separately mentioned in the Special Conditions of Contract.

  • Construction waste means solid waste which is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings, and other structures. Construction wastes include, but are not limited to lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, paving materials, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids and garbage are not construction wastes.

  • Construction and demolition debris means and includes:

  • Construction Activities means the disturbance of soils associated with clearing, grading, excavation activities or other construction-related activities.

  • Existing Facilities means all existing buildings and other facilities, the sites for the buildings or facilities, and furnishings or equipment for the buildings or facilities located on real property acquired by the building authority under the terms of this act.

  • Subproject means a specific development project to be carried out by a Beneficiary under Part B.2 of the Project and to be financed out of the proceeds of a Matching Grant.

  • Constructional Plant means all appliances or things whatever nature required in or about the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work or temporary housing, hutting, office, stores, etc.,

  • Common Facilities means the facilities under D.G.sets/D.G.rooms, water storage tanks its pumping and supply system, sewerage & drainage systems, electric sub-station/ transformers/electric panels/distribution network, maintenance service rooms, lawns including lighting & services etc., roads, pathways & driveways including street lighting & services etc., guard posts, fire hydrants & fire fighting system etc. and all such facilities and areas for common use and excluded from the computation of Super Area of the Said Premises;

  • Completion of Construction means the date, as determined by the Division after consultation with the Recipient, that the work of building and erection of the Project is substantially complete.

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which: