Contractual Date definition

Contractual Date means the earliest date on which the customer accepts an Order (which may be before the Service Delivery Date) and/or receives any Purchased Equipment.
Sample 1Sample 2Sample 3
Contractual Date means any date specified for the fulfilment of Contractual obligations in schedule E which is identified as a Contractual Date therein and the Acceptance Completion Date of the System, which shall be a Contractual Date whether identified in schedule E as such or not;
Sample 1Sample 2
Contractual Date means the earliest date on which the customer accepts an Order and/or receives any Equipment.
Sample 1

Examples of Contractual Date in a sentence

  • Without limiting the foregoing or any remedies available to the holders of Rights, it is specifically acknowledged and agreed that the holders of Rights would not have an adequate remedy at law for any breach of this Agreement and shall be entitled to specific performance of the obligations under this Agreement and injunctive relief against actual or threatened violations of the obligations under this Agreement of any Person subject to this Agreement.

  • After designs and Construction Documents are sufficiently developed, and upon request of the ADR, Design-Builder shall submit for UGAA review and approval a proposed GMP Change Order to establish the GMP, which shall be inclusive of the Cost of the Work, Design-Builder Construction Fee, Design- Builder Contingency Account, and Design-Builder Construction Overhead Costs – all as necessary to complete the Work on or before the Contractual Date of Substantial Completion.

  • The Parties anticipate, and all prospective Project-related schedules will provide for, and the Contractual Date of Substantial Completion takes into account, the following number of days of Adverse Weather in each of the respective months: January (7 days); February (7 days); March (7 days); April (6 days); May (6 days); June (3 days); July (4 days); August (4 days); September (3 days); October (4 days); November (7 days); and December (7 days) (collectively, “Anticipated Adverse Weather Days”).

  • Contractual Date for Teacher Notification of Tentative Assignment As soon as feasible, but not later than May 15 Not later than May 15 for Tracks A, B, C Not later than April 13 for Track D + Principal and UTLA Chapter Chair may jointly develop alternative dates* Refer to Article IX-A, Sections 4.0-9.0** Chapter Chair elections are to be conducted by UTLA.

  • The Parties anticipate, and all prospective Project-related schedules will provide for, and the Contractual Date of Substantial Completion takes into account, the following number of days of Adverse Weather in each of the respective months: January (14 days); February (14 days); March (10 days); April (7 days); May (6 days); June (3 days); July (4 days); August (4 days); September (3 days); October (3 days); November (5 days); and December (9 days) (collectively, “Anticipated Adverse Weather Days”).

  • Contractual Date – the date that the customer and their broker agree to settle the transaction.

  • If the Builder does not provide such notice before the expiry of the deadline (no later than 30 calendar days after the Buyer has declared the option and in any event before the shipbuilding contract for the option vessel is signed), the delivery date shall be the delivery date stated in Box 28 (7 months after the Contractual Date of Delivery in this Contract).

  • After designs and Construction Documents are sufficiently developed, and upon request of the ADR, CM shall submit for UGAA review and approval a proposed GMP Change Order to establish the GMP, which shall be inclusive of the Cost of the Work, CM Construction Fee, CM Contingency Account, and CM Construction Overhead Costs – all as necessary to complete the Work on or before the Contractual Date of Substantial Completion.

  • H.3.3 In the event the Work is not substantially completed by the Contractual Date of Substantial Completion, which is defined as the date when work per the Contract Documents is complete to the point where the Courts can fully, safely, and securely commence work in the Project Area, the Contractor, its agents and subcontractors shall be liable to the Courts for liquidated damages for each calendar day thereafter until the Contractor reaches Substantial Completion.

  • Contractual Date for Teacher Notification of Tentative Assignment As soon as feasible, but not later than May 15Not later than May 15 for Tracks A, B, C Not later than April 13 for Track D + Principal and UTLA Chapter Chair may jointly develop alternative dates* Refer to Article IX-A, Sections 4.0-9.0** Chapter Chair elections are to be conducted by UTLA.


More Definitions of Contractual Date

Contractual Date means the date of the issuance of Purchase Order by the Purchaser.
Sample 1

Related to Contractual Date

  • Extra Contractual Obligations shall be defined as those liabilities not covered under any other provision of this Contract and that arise from the handling of any claim on business covered hereunder, such liabilities arising because of, but not limited to, the following: failure by the Company to settle within the Policy limit, or by reason of alleged or actual negligence, fraud or bad faith in rejecting an offer of settlement or in the preparation of the defense or in the trial of any action against its insured or reinsured or in the preparation or prosecution of an appeal consequent upon such action.

  • Contractual Service means the rendering by a contractor of its time and effort rather than the furnishing of specific commodities. The term applies only to those services rendered by individuals and firms who are independent contractors. Contractual Services do not include auditing services, Maintenance Services, or Professional Services as defined in Section 287.055(2)(a) of the Florida Statutes, and these Rules. Contractual Services also do not include any contract for the furnishing of labor or materials for the construction, renovation, repair, modification, or demolition of any facility, building, portion of building, utility, park, parking lot, or structure or other improvement to real property entered into pursuant to Chapter 255 of the Florida Statutes, and Rules 3.5 or 3.6.

  • Contractual Delivery Date means the stipulated date on which the contractor shall attain

  • Contractual Obligation means, as to any Person, any provision of any security issued by such Person or of any agreement, instrument or other undertaking to which such Person is a party or by which it or any of its property is bound.

  • Contractual Obligations means, as to any Person, any provision of any security issued by such Person or of any agreement, undertaking, contract, indenture, mortgage, deed of trust or other instrument, document or agreement to which such Person is a party or by which it or any of its Property is bound.

  • BREACH OF CONTRACTUAL OBLIGATION means amongst others also the following:

  • Contractual Services are defined as those specified services established within the OAG approved budget for which the Provider is to be paid upon completion at the set rate also established within the OAG approved budget, as authorized expenditures eligible for payment, or reimbursement pursuant to ARTICLE 9, AUTHORIZED EXPENDITURES, of this Agreement.

  • Contractual Requirement shall have the meaning provided in Section 8.3.

  • Standard Contractual Clauses means the clauses attached hereto as Exhibit 1 pursuant to the European Commission’s decision (C(2010)593) of 5 February 2010 on Standard Contractual Clauses for the transfer of personal data to processors established in third countries which do not ensure an adequate level of data protection.

  • Pre-Contractual Statement means a draft agreement, undertaking, representation, warranty, promise, assurance or arrangement of any nature whatsoever, whether or not in writing, relating to this Agreement made or given by a Party to this Agreement or any other person at any time prior to the date of this Agreement.

  • EU Standard Contractual Clauses means: (i) the standard contractual clauses adopted by the European Commission on 4th June 2021 or (ii) such other standard contractual clauses that are approved by the European Commission for Controller to Processor transfers of Personal Data to a third country which has not received an EU Adequacy Decision (and are subsequently incorporated into the DPA). GDPR means the EU General Data Protection Regulation being Regulation (EU) 2016/679.

  • Continuing Arrangements means those arrangements set forth on Schedule 1.1(24) and such other commercial arrangements among the Parties that are intended to survive and continue following the Separation Time; provided, however, that for the avoidance of doubt, Continuing Arrangements shall not be Third Party Agreements.

  • Signing Date means the Original Issue Date.

  • netting arrangement means an arrangement under which a number of claims or obligations can be converted into a single net claim, including close-out netting arrangements under which, on the occurrence of an enforcement event (however or wherever defined) the obligations of the parties are accelerated so as to become immediately due or are terminated, and in either case are converted into or replaced by a single net claim, including ‘close-out netting provisions’ as defined in point (n)(i) of Article 2(1) of Directive 2002/47/EC and ‘netting’ as defined in point (k) of Article 2 of Directive 98/26/EC;

  • Swap Agreements means, collectively, each Asset Swap Agreement, Liability Swap Agreement and any other swap agreement that may be entered into in connection with the Programme;

  • Group contract means a contract for health care services which by its terms limits eligibility to members of a specified group. The group contract may include coverage for dependents.

  • Specified Agreements means agreements relating to the following matters, namely:

  • PASS-THRU ENTITY A "Pass-Thru Entity" as defined in Section 860E(e)(6) of the Code.

  • Swap Agreement means any agreement with respect to any swap, forward, future or derivative transaction or option or similar agreement involving, or settled by reference to, one or more rates, currencies, commodities, equity or debt instruments or securities, or economic, financial or pricing indices or measures of economic, financial or pricing risk or value or any similar transaction or any combination of these transactions; provided that no phantom stock or similar plan providing for payments only on account of services provided by current or former directors, officers, employees or consultants of the Borrower or the Subsidiaries shall be a Swap Agreement.

  • Operating Documents are, for any Person, such Person’s formation documents, as certified by the Secretary of State (or equivalent agency) of such Person’s jurisdiction of organization on a date that is no earlier than thirty (30) days prior to the Effective Date, and, (a) if such Person is a corporation, its bylaws in current form, (b) if such Person is a limited liability company, its limited liability company agreement (or similar agreement), and (c) if such Person is a partnership, its partnership agreement (or similar agreement), each of the foregoing with all current amendments or modifications thereto.

  • Permitted Entity means with respect to a Qualified Stockholder (a) a Permitted Trust (as defined below) solely for the benefit of (i) such Qualified Stockholder, (ii) one or more Family Members of such Qualified Stockholder and/or (iii) any other Permitted Entity of such Qualified Stockholder, or (b) any general partnership, limited partnership, limited liability company, corporation or other entity exclusively owned by (i) such Qualified Stockholder, (ii) one or more Family Members of such Qualified Stockholder and/or (iii) any other Permitted Entity of such Qualified Stockholder.

  • Lock-Up Agreements means the lock-up agreements that are delivered on the date hereof by each of the Company’s officers and directors, in the form of Exhibit A attached hereto.

  • Continuing Contract means a contract for Professional Services entered into in accordance with Section 287.055 of the Florida Statutes, between the District and a firm, whereby the firm provides Professional Services to the District for projects in which the costs do not exceed two million dollars ($2,000,000), for a study activity when the fee for such Professional Services to the District does not exceed two hundred thousand dollars ($200,000), or for work of a specified nature as outlined in the contract with the District, with no time limitation except that the contract must provide a termination clause (for example, a contract for general District engineering services). Firms providing Professional Services under Continuing Contracts shall not be required to bid against one another.

  • Specified Swap Agreement any Swap Agreement entered into by the Borrower and any Qualified Counterparty (or any Person who was a Qualified Counterparty as of the Closing Date or as of the date such Swap Agreement was entered into) in respect of interest rates to the extent permitted under Section 7.13.

  • Restricted Parties has the meaning set forth in Section 6.7(a).

  • Actual conflict of interest means any action or any decision or recommendation by a person acting in a capacity as a public official, the effect of which would be to the private pecuniary benefit or detriment of the person or the person's relative or any business with which the person or a relative of the person is associated unless the pecuniary benefit or detriment arises out of circumstances described in subsection (7) of this section.”