CREMA Subproject means any of the works under each CREMA Contract (as said term is defined herein).
CREMA Subproject means any of the investments referred to in Part B of the Project;
Subproject means a specific project to be carried out by an existing BE utilizing the proceeds of a Sub-loan or Investment, as hereinafter defined, fulfilling the conditions set forth in Part A of Schedule 4 to this Agreement;
Capital Improvement Project means the acquisition, construction, reconstruction, improvement, planning and equipping of roads and bridges, appurtenances to roads and bridges to enhance the safety of animal-drawn vehicles, pedestrians, and bicycles, wastewater treatment facilities, water supply systems, solid waste disposal facilities, and storm water and sanitary collection, storage and treatment facilities including real property, interests in real property, facilities, and equipment related or incidental to those facilities.
Cannabis testing facility means an entity registered by
Temporary clean coal technology demonstration project means a clean coal technology demonstration project that is operated for a period of five years or less and that complies with the SIP and other requirements necessary to attain and maintain the national ambient air quality standards during the project and after the project is terminated.
The Works/Project means the works to be executed or done under this contract.
Development Project means a project for the development of land within a project area.
Project Completion Date means the date on which the Completion Certificate is issued;
Pilot project means an innovative environmental project that covers one or more designated facilities, designed and implemented in the form of an EMSA. (See Section 52.3 of the Act.)
Maximum medical improvement means a point in time when any medically
Redevelopment project means a specific construction project
Cost of Capital Improvement Projects means the costs of acquiring, constructing, reconstructing, expanding, improving and engineering Capital Improvement Projects, and related financing costs.
Infrastructure improvement means permanent infrastructure that is essential for the public health and safety or that:
Clean coal technology demonstration project means a project using funds appropriated under the heading “Department of Energy—Clean Coal Technology,” up to a total amount of $2,500,000,000 for commercial demonstration of clean coal technology, or similar projects funded through appropriations for the Environmental Protection Agency. The federal contribution for a qualifying project shall be at least 20 percent of the total cost of the demonstration project.
Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.
Generation Interconnection Feasibility Study means a study conducted by the Transmission Provider (in coordination with the affected Transmission Owner(s)) in accordance with Tariff, Part IV, section 36.
Power plant means a facility for the generation of
Solar PV Project means the solar Photo Voltaic Power project that uses sunlight for direct conversion into electricity through Photo Voltaic technology.
Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).
Generation Interconnection Facilities Study means a Facilities Study related to a Generation Interconnection Request.
Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.
Project means the goods or Services described in the Signature Document or a Work Order of this Contract.
Project Engineer means the surveyor or engineer employed by or private
Planned special exposure means an infrequent exposure to radiation, separate from and in addition to the annual occupational dose limits.
NCZ Examined Project means any Generator or UDR project that is not exempt pursuant to 23.4.5.7.8 and either (i) is in a Class Year on the date the Commission accepts the first ICAP Demand Curve to apply to a Mitigated Capacity Zone or (ii) meets the criteria specified in 23.4.5.7.3(II). An NCZ Examined Project may be at any phase of development or in operation or an Installed Capacity Supplier.For purposes of Section 23.4.5 of this Attachment H, “Net CONE” shall mean the localized levelized embedded costs of a peaking unit in a Mitigated Capacity Zone, net of the likely projected annual Energy and Ancillary Services revenues of such unit, as determined in connection with establishing the Demand Curve for a Mitigated Capacity Zone pursuant to Section 5.14.1.2 of the Services Tariff, or as escalated as specified in Section 23.4.5.7 of Attachment H.
Cost of the Project means and embraces the cost of construction; the cost of all
Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).