Criteria Architect definition

Criteria Architect means the architectural firm engaged as an agent by the Judicial Council to prepare the Performance Criteria documents, and to review the design documents to ensure compliance with the Performance Criteria documents. The Criteria Architect’s team may include additional consultants (“Criteria Team”) to aid in development of Performance Criteria documents and review of the design documents for adherence to the Performance Criteria documents.
Sample 1Sample 2Sample 3
Criteria Architect means the consultant retained by CDCR to develop the Criteria Documents and define functional and aesthetic characteristics establishing the design intent.
Sample 1Sample 2
Criteria Architect. Salas O’Brien, the architect retained by the District to develop the Criteria Documents and define functional, performance and aesthetic characteristics establishing the design intent for the Project.
Sample 1Sample 2

Examples of Criteria Architect in a sentence

  • Criteria Architect specifically acknowledges that in entering this Agreement, Criteria Architect relies solely upon the provisions contained in this Agreement and no others.

  • Notwithstanding the provisions hereinabove set forth, Work performed by employees of Criteria Architect in excess of eight (8) hours per day and forty (40) hours during any one week, shall be permitted upon this public work upon compensation for all hours worked in excess of eight (8) hours per day at not less than one and one-half times the basic rate of pay.

  • Criteria Architect and its Subconsultants presently have no interest and will not acquire any interest which would present a conflict of interest pursuant to California Government Code sections 1090 et seq.

  • This will be the only amount(s) potentially owing to Criteria Architect if there is a termination for convenience.

  • Criteria Architect, by signing the Agreement, hereby acknowledges the applicability of Government Code section 16645 through section 16649 to the Agreement.

  • Criteria Architect will not assist, promote, or deter union organizing by employees performing work on a Judicial Council contract, including a public works contract.

  • Time is of the essence and failure of Criteria Architect to perform the Work on time as specified in this Agreement is a material breach of this Agreement.

  • Criteria Architect shall provide the Services described herein and under Exhibit B for the Project.

  • Criteria Architect and employees of the Criteria Architect must also avoid actions resulting in or creating the appearance of: Use of an official position with the government for private gain; Preferential treatment to any particular person associated with this Agreement or the Work of this Agreement; Loss of independence or impartiality; Impropriety; A decision made outside official channels; or Adverse effects on the confidence of the public in the integrity of the government or this Agreement.

  • This Agreement is intended to secure the specialized services of the Criteria Architect.


More Definitions of Criteria Architect

Criteria Architect the architect, ED2 International Architects and Planners, retained by the District to develop the Criteria Documents and define functional, performance and aesthetic characteristics establishing the design intent for the Project.
Sample 1
Criteria Architect the architect, Lionakis, retained by the District to develop the Criteria Documents and define functional, performance and aesthetic characteristics establishing the design intent for the Project.
Sample 1

Related to Criteria Architect

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.

  • Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.

  • Design Criteria Professional means a firm who holds a current certificate of registration under Chapter 481 of the Florida Statutes, to practice architecture or landscape architecture, or a firm who holds a current certificate as a registered engineer under Chapter 471 of the Florida Statutes, to practice engineering, and who is employed by or under contract to the District to provide professional architect services, landscape architect services, or engineering services in connection with the preparation of the Design Criteria Package.

  • Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.

  • Architect/Engineer (A/E means a person registered as an architect pursuant to Tex. Occ. Code Ann., Ch. 1051, as a landscape architect pursuant to Tex. Occ. Code Ann., Ch. 1052, a person licensed as a professional engineer pursuant Tex. Occ. Code Ann., Ch. 1001, and/or a firm employed by Owner or Design-Build Contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.

  • Project Engineer means the surveyor or engineer employed by or private

  • Design Criteria Package means concise, performance-oriented drawings or specifications for a public construction project. The purpose of the Design Criteria Package is to furnish sufficient information to permit Design-Build Firms to prepare a bid or a response to the District’s Request for Proposals, or to permit the District to enter into a negotiated Design- Build Contract. The Design Criteria Package must specify performance- based criteria for the public construction project, including the legal description of the site, survey information concerning the site, interior space requirements, material quality standards, schematic layouts and conceptual design criteria of the project, cost or budget estimates, design and construction schedules, site development requirements, provisions for utilities, stormwater retention and disposal, and parking requirements applicable to the project. Design Criteria Packages shall require firms to submit information regarding the qualifications, availability, and past work of the firms, including the partners and members thereof.

  • Professional Engineer means a person entitled to practise as a Professional Engineer in the Province of Ontario under a licence issued under the Professional Engineers Act;

  • Architect/ consultants means and refer to the Consultants appointed by NU as Architect Consultants.

  • Independent Engineer means XxXxxxxx and XxxXxxxxxxx or any other third party engineering firm acceptable to the Administrative Agent in its sole discretion.

  • Practice of architecture means professional services, such as consultation, investigation, evaluation, planning, design, or review of material and completed phases of work in construction, alteration, or repair in connection with a public or private structure, building, equipment, works, or project if the professional service requires the application of a principle of architecture or architectural design.

  • Structural Engineer means the Engineer appointed or to be appointed from time to time by Promoter for the preparation of the structural design and drawings of the buildings .

  • Improvement completion assurance means a surety bond, letter of credit,

  • Architectural Review Committee or “ARC” shall mean the architectural review committee established by the Organization to review plans submitted to the Organization for architectural review.

  • Design Criteria means the design criteria set out in the Ministry’s publication “Design Criteria for Sanitary Sewers, Storm Sewers and Forcemains for Alterations Authorized under Environmental Compliance Approval”, (as amended from time to time).

  • Engineer means the representative of the Architect/consultant.

  • Design engineer means a person professionally qualified and duly licensed in New Jersey to perform engineering services that may include, but not necessarily be limited to, development of project requirements, creation and development of project design and preparation of drawings and specifications.

  • Non-Participating Certified Clinical Nurse Specialist means a Certified Clinical Nurse Specialist who does not have a written agreement with the Claim Administrator or another Blue Cross and/or Blue Shield Plan to provide services to you at the time services are rendered.

  • Licensed Professional Engineer means a person acceptable to Buyer in its reasonable judgment who (a) is licensed to practice engineering in California, (b) has training and experience in the power industry specific to the technology of the Project, (c) has no economic relationship, association, or nexus with Seller or Buyer, other than to meet the obligations of Seller pursuant to this Agreement, (d) is not a representative of a consultant, engineer, contractor, designer or other individual involved in the development of the Project or of a manufacturer or supplier of any equipment installed at the Project, and (e) is licensed in an appropriate engineering discipline for the required certification being made.

  • Construction Consultant means a third-party architect or engineer selected and retained by Funding Lender, at the cost and expense of Borrower, to monitor the progress of construction and/or rehabilitation of the Project and to inspect the Improvements to confirm compliance with this Borrower Loan Agreement.

  • Registered professional engineer means a person who is registered as a professional engineer pursuant to s. 443.04, Stats.

  • Geotechnical engineer means a professional engineer registered with the Association of Professional Engineers, Geologists, and Geophysicists of the Northwest Territories and whose principal field of specialization is the design and construction of earthworks in a permafrost environment;

  • Design Professional means architect or engineer.

  • Professional Engineer or Professional Certificated Engineer means a person holding registration as either a Professional Engineer or Professional Certificated Engineer in terms of the Engineering Profession Act, 2000 (Act No. 46 of 2000);