Environmental Defect means, with respect to any given Asset, a material violation of Environmental Laws in effect as of the Effective Time in the jurisdiction in which such Asset is located.
Environmental Defect Notice shall have the meaning set forth in Section 12.1(a).
Defect Notice shall have the meaning specified in Section 3.2 of this Agreement.
Title Defect as used herein shall mean any encumbrance, encroachment, irregularity, defect in or objection to Seller’s title to the Leases and Xxxxx (excluding Permitted Encumbrances) which would result in Seller not having Defensible Title.
Title Defect Notice shall have the meaning set forth in Section 11.2(a).
Title Defects has the meaning set forth in Section 5.15(b).
Construction defect means a deficiency in or a deficiency arising out of the design, specifications, surveying, planning, supervision, or observation of construction or construction of residential improvements that results from any of the following:
Title Defect Property has the meaning set forth in Section 6.2(a).
Latent Defect means a defect, inherently lying within the material or arising out of design deficiency, which do not manifest themselves and/or was not reasonably discoverable during Defect Liability period.
Environmental Defect Value means, with respect to any Environmental Defect, the value, as of the Closing Date, of the estimated costs and expenses to correct such Environmental Defect in the most cost-effective manner reasonably available, consistent with Environmental Laws, taking into account that non-permanent remedies (such as mechanisms to contain or stabilize hazardous materials, including monitoring site conditions, natural attenuation, risk-based corrective action, institutional controls or other appropriate restrictions on the use of property, caps, dikes, encapsulation, leachate collection systems, etc.) may be the most cost-effective manner reasonably available.
Latent Defects means such defects caused by faulty designs, material or work man ship which cannot be detected during inspection, testing etc, based on the technology available for carrying out such tests.
Minor defect means a defect which is not a Major Defect.
Title Defect Amount means, with respect to a Title Defect Property, the amount by which such Title Defect Property is impaired as a result of the existence of one or more Title Defects, which amount shall be determined as follows:
Defective Work means (a) Work that is unsatisfactory, deficient or damaged, does not conform to the Contract Documents, or does not meet the requirements of any inspection, test or approval, or (b) Work associated with punch list items that the Contractor fails to complete within a reasonable time after issuance of the punch list by the Project Manager.
Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.
Environmental Condition means any condition or circumstance, including the presence of Hazardous Substances which does or would (i) require assessment, investigation, abatement, correction, removal or remediation under any Environmental Law, (ii) give rise to any civil or criminal Liability under any Environmental Law, (iii) create or constitute a public or private nuisance or (iv) constitute a violation of or non-compliance with any Environmental Law.
Major Damage means damage that in the estimation of the surveyor exceeds USD
Nonconformance as used in this clause means a condition of any hardware, software, material, or service/workmanship in which one or more characteristics do not conform to requirements.
Punchlist Items means any items necessary at the time of the issuance of a temporary certificate of occupancy to complete fully the renovation of the Project Facilities in accordance with the Plans and Specifications for the Project Facilities, or required for the issuance of a final certificate of occupancy or its equivalent.
Punch List Items means such items (i) as are reasonably necessary or appropriate to fully complete the construction, equipping and furnishing of the Hotel in accordance with this Contract and (ii) that, unless otherwise agreed by Buyer in its sole discretion, (a) individually and in the aggregate do not and will not prohibit, cause a delay in or otherwise adversely affect, under applicable Legal Requirements, the Franchise Agreement or otherwise, the opening of the Hotel for business to the public or the continued occupancy and operation of the Hotel as contemplated under the Brand and (b) may be corrected or completed, subject to delays caused by Force Majeure, within not more than sixty (60) days.
Environmental Conditions means any conditions of the environment, including, without limitation, the work place, the ocean, natural resources (including flora or fauna), soil, surface water, ground water, any actual or potential drinking water supply sources, substrata or the ambient air, relating to or arising out of, or caused by the use, handling, storage, treatment, recycling, generation, transportation, Release or threatened Release or other management or mismanagement of Regulated Substances resulting from the use of, or operations on, the Property.
Nonconforming zoning condition means a physical improvement on a property that does not conform with current zoning standards.
Nonconformity or “Nonconformities” means any failure or failures of the Software to conform to the requirements of this Contract, including any applicable Documentation.
Material Defect As defined in Section 2.02(c) hereof.
Defects Liability Period (Warranty Period) means the period stated in the Schedule A Special Stipulations, following the taking over, during which the Contractor is responsible for making good defects and damage in accordance with Clause 15.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.