Escrow Completion definition

Escrow Completion means completion of the matters set out at clause 6.2 and clause 6.3, subject to satisfaction of the Escrow Condition;
Sample 1Sample 2
Escrow Completion has the meaning given to it in clause 9.1;
Sample 1
Escrow Completion means completion of the sale and purchase of the Non-ISP Interests in accordance with the terms of this agreement subject to the Escrow Condition;
Sample 1

Examples of Escrow Completion in a sentence

  • In these circumstances, the Company undertakes to procure that Ballynatray executes a transfer of its legal interest in the Redstone Shares held by it to the Company prior to Escrow Completion.

  • At Escrow Completion, the parties shall do those things ascribed to them in Schedule 3 subject to the Escrow Condition.

  • This will address the experience of the Tenderer as well as the capability and qualifications of the key personnel who will be operating under the contract, including the management and supervisory backup.

  • We refer to these agencies as “Direct- Service State agencies.” Nearly all ITOs and territories and seven States reported providing direct services to WIC participants.

  • Escrow Completion shall take place (the "Escrow Completion") on the date which is five Business Days after the date (not being later than the Longstop Date) on which the last of the Conditions (other than the FCA Admission Condition and the LSE Admission Condition) has been satisfied (or, if capable of being waived, waived) (the "Escrow Completion Date").

  • CollaGenex shall provide to Alliance, a letter fairly disclosing any fact or circumstance which constitutes, or which but for the giving of notice or passage of time might constitute as at Escrow Completion, a breach of any of the warranties contained in Article 7 of this Agreement (the “Disclosure Letter”).

  • A final inspection certificate from the appraiser, a Repair Escrow Completion Letter from the Owner stating all work has been satisfactorily completed and a Conditional Waiver & Release document must be received by the Lender within 60 days of closing the loan.

  • Buyer and Parent will use their commercially reasonable efforts to take or cause to be taken all actions and to do or cause to be done all things necessary under the terms of this Agreement or under applicable Laws to (a) consummate the transactions contemplated by the Escrow Completion and (b) satisfy the conditions to Closing and to consummate the transactions contemplated by this Agreement as soon as reasonably possible and in any event on or prior to the Closing Date.

  • To the extent that, at Escrow Completion, the Purchaser or the Company has not complied with its obligations under schedule 3, the Offeror shall, to the extent practicable, exercise its power of attorney under clauses 6.4 and 6.5 to effect Escrow Completion.

  • The Purchaser shall provide such documents to, and take all other actions reasonably required by, the FCA and the London Stock Exchange in order to procure that the Existing Purchaser Shares are re-admitted and the New Purchaser Shares are admitted, in each case to the premium listing segment of the Official List of the FCA and to trading on the main market for listed securities of the London Stock Exchange on the second Business Day following the Escrow Completion Date.


More Definitions of Escrow Completion

Escrow Completion has the meaning given to it in the Escrow Notice" Agreement;
Sample 1
Escrow Completion means the delivery of the Escrow Documents by Seller to Buyer’s Attorneys to hold in accordance with the provisions of Section 2.2.
Sample 1
Escrow Completion has the meaning given to it in Clause 11.1; Estimated Liability the amount of the Pending Claim; Existing Loan Agreement the convertible loan agreement entered into by and Existing Outstanding Amount Existing Sellers the holders of the Existing Shares, as set out in Existing Shares the Ordinary Shares set out in column 2 of part 1 Expert has the meaning in Clause 14.3(a); FA followed by the year means the Finance Act of that year; FRS Financial Reporting Standards issued by the Accounting Standards Board; Fundamental Warranties the warranties contained in Schedule 5; Fundamental Warranty Claim Further Investment Agreement General Meeting the general meeting of the shareholders of the HS Laws all applicable laws, statutes, regulations, subordinate legislation, bye-laws, common law and other national, international, federal, European Union, state and local laws, judgments, decisions and injunctions of any court or tribunal and legally binding codes of practice and guidance notes to the extent that they relate to or apply to the health and safety of any person; HS Matters all matters relating to the health and safety of any person, including any accidents, injuries, illnesses and diseases; HS Permits any permits, licences, consents, certificates, registrations, notifications or other authorisations required under any HS Laws for the operation of the Business; IHTA Inheritance Tax Xxx 0000; Indebtedness means:
Sample 1
Escrow Completion means completion of the matters set out in clause 5.2 subject only to fulfilment of the Conditions;
Sample 1
Escrow Completion shall have the meaning in Clause 6.1;
Sample 1
Escrow Completion means the date on which completion occurs in escrow as contemplated in clause 7.1;
Sample 1

Related to Escrow Completion

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Practical Completion means the completion of the Project where the building is fit for occupancy and/or purpose.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Escrow Holder means the bank or trust company designated as such pursuant to Section 9 hereof.

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Certificate of Final Completion means the certificate issued by A/E that documents, to the best of A/E’s knowledge and understanding, Contractor’s completion of all Contractor’s Punchlist items and pre-final Punchlist items, final cleanup and Contractor’s provision of Record Documents, operations and maintenance manuals, and all other closeout documents required by the Contract Documents.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Close of Escrow or “Closing” means the date Escrow Holder records the Deed in favor of Buyer. The Closing shall take place on the Closing Date set forth in Section 1.5.1, as the same may be extended, provided all conditions to the Closing have been satisfied or duly waived as provided herein.