Excusable Tenant Delay definition

Excusable Tenant Delay means any Tenant delay that is caused by or attributable to (but only to the extent of) a Force Majeure Event. No Tenant delay arising from the failure to make funds available for any purpose shall ever be an Excusable Tenant Delay unless such failure, inability or refusal itself arises directly from, and is based upon, another event or circumstance which is an Excusable Tenant Delay.
Sample 1Sample 2Sample 3
Excusable Tenant Delay means any the Tenant Delay which is caused by or attributable to (but only to the extent of) Force Majeure. No Tenant Delay arising from the failure to make funds available for any purpose shall ever be an Excusable Tenant Delay unless such failure, inability or refusal itself arises directly from, and is based upon, another event or circumstance which is an Excusable Tenant Delay.
Sample 1Sample 2

Examples of Excusable Tenant Delay in a sentence

  • Such a work stoppage shall not constitute an Excusable Tenant Delay.

  • If any member who has access to confidential information or data knowingly breaches the law relating (but not limited to), the unauthorised disclosure of confidential information, they may be personally liable.

  • Tenant shall design, develop and construct, or have designed, developed and constructed, the Project Improvements within the Leased Premises in accordance with the terms and conditions of Project Plans, this Lease and all Applicable Laws, and shall use commercially reasonable efforts to adhere to the Project Construction Schedule (subject to any Excusable Tenant Delay and/or Landlord Delay permitted in accordance with the terms of this Lease), in each case, at Tenant’s sole cost, risk and expense.

  • Upon consummation of the Cash-Out Merger Buyer shall assume the obligations of Seller under, and upon consummation of the Bank Merger.

  • During the Term, Tenant covenants to conduct or cause to be conducted all elements of any Additional Work diligently and continuously, subject only to interruptions and delays caused by Excusable Tenant Delay or Landlord Delay, and in a manner consistent with the requirements of this Article XII.

  • Toward that end, Tenant and City each hereby agrees that it shall make all reasonable efforts to prevent and reduce to a minimum and mitigate the effect of any Tenant delay or City delay occasioned by an Excusable Tenant Delay or Excusable City Delay, and shall diligently and continuously use its commercially reasonable efforts to ensure resumption of performance of its obligations under this Agreement after the occurrence of any Excusable Tenant Delay or Excusable City Delay.

  • Examples: One-Way, Dead End, Stop Ahead, Curve Ahead• Guide Signs: Used to guide motorists.

  • Landlord and Tenant hereby acknowledge and agree that, as of the Effective Date of this First Amendment, no Excusable Tenant Delay or Excusable Tenant Delay Period has occurred during the Term.

  • Tenant shall give Landlord reasonable Notice (which in no event shall be less than ten (10) days) of its intent to carry on such contest, specifying the Applicable Laws that Tenant proposes to contest, the name of counsel representing Tenant in such contest and the Excusable Tenant Delay, if any, that such contest will cause in any repair, alteration or improvement of the Project Improvements.

  • Only one (1) notice from Tenant shall be required with respect to a continuing Excusable Tenant Delay, except that Tenant shall promptly (and in no event less often every thirty (30) days) give notice to Authority Representative of any further changes in the additional time for performance claimed by reason of the continuing delay.

Related to Excusable Tenant Delay

  • Tenant Delay means (i) any request by Tenant that Landlord delay in the commencement or completion of the Premises Base Building Work, or the Common Facilities Base Building Work, as applicable, for any reason; (ii) any delay in the Base Building Substantial Completion Date caused by Tenant’s contractors, agents and employee’s interference with Landlord and Landlord’s contractor’s, agents, and employees; or (iii) any other act or omission of Tenant or its officers, agents, servants or contractors which causes a delay in the Premises Base Building Work, or the Common Facilities Base Building Work, as applicable. If a delay shall occur in the Base Building Work as a result of Tenant Delay, then Tenant shall, within thirty (30) days after determination of the Rent Commencement Date, and only to the extent that such amount exceeds the rent credit, if any, due to Tenant, pay to Landlord for each day of Tenant’s Delay the amount of Basic Rent, Additional Rent and other charges that would have been payable hereunder had Tenant’s Delay not occurred to the extent that such Tenant Delay caused the Rent Commencement Date to be later than the date such date would have occurred had such Tenant Delay not occurred. Landlord shall give Tenant written notice of a Tenant Delay under clauses (ii) and (iii) above within twenty-four (24) hours after Landlord learns of such Tenant Delay. Subject to Tenant Delay and Force Majeure, if Landlord shall have failed to substantially complete the Premises Base Building Work on or before March 1, 2002, Tenant shall have the right to terminate the Lease by written notice to Landlord prior to March 15, 2002, whereupon this Lease shall terminate and be of no further force or effect thirty (30) days after the date of such notice unless Landlord shall have substantially completed the Premises Base Building Work prior to, or within such period.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Work loss means loss of income from work the injured victim would have performed if the injured victim had not been injured and expenses reasonably incurred by the injured victim in obtaining services in lieu of those the injured victim would have performed for income,

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Event of Force Majeure means one of the following events:

  • Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).