Final Occupancy definition

Final Occupancy means when all outstanding items on a partial Occupancy including grading have been completed;
Sample 1Sample 2Sample 3
Final Occupancy. Shall be defined as the substantial completion of all works and finishes of the interior part of the industrial area and office area, as well as all the exterior parts and infrastructure of the LESSOR Improvements, in order to allow the LESSEE to make use of the Leased Property to commence normal unfolding of its operations unhindered, excluding non functional aesthetical issues or the punch list, without exceeding the amount of $66,000.00 Dollars, legal currency of the United States of America, regarding the construction costs of the LESSOR Improvements, in compliance with what is stated in Attachment "B" herein. In the event the cost for the construction of what is stated in the punch list exceeds the amount of $66,000.00 Dollars, legal currency of the United States of America, the date of the Final Occupancy shall be deferred in accordance with what is stated in Clause 2.
Sample 1

Examples of Final Occupancy in a sentence

  • All project improvements, including compliance with applicable codes, conditions, and requirements of all departments and agencies with jurisdiction over the project, shall be completed prior to granting of a Certificate of Final Occupancy by the Local Agency Building Official, which, upon granting, authorizes all use and permit activities to commence.

  • The Purchaser hereby waives the obligation of the Vendor to provide Thirty (30) days’ advance notice of the Confirmed Final Occupancy Date, and the Purchaser agrees that closing shall otherwise occur in accordance with the Purchase Contract on the Confirmed Final Occupancy Date as stated above.

  • The Certified Professional can recommend Final Occupancy and/or issuance of Occupancy Permit but cannot authorize occupancy of a building.

  • For more information, refer to the following web pages:https://www.abbotsford.ca/business_and_development/building_permits/b uilding_inspection.htm https://www.abbotsford.ca/business_and_development/building_permits/d ocumentation_meeting.htm The Certified Professional can recommend Final Occupancy and/or issuance of Occupancy Permit but cannot authorize occupancy of a building.

  • A certification of completion from the Landscape Architect is required prior to Final Occupancy of the project.

  • However, all tenant/landlord improvements that are in‐stream will require the Certified Professional’s site review until the works related to the tenant/landlord improvement permits are complete.A building will be given Final Occupancy (Occupancy Permit) once all the works related to tenant/landlord improvement permits have been completed and accepted (See Appendix for the checklist).

  • For all projects, field review reports are collected by the Certified Professional through the Coordinating Registered Professional and compiled as the record of satisfactory progress for the Final Occupancy of the project.

  • All project improvements, including compliance with all applicable codes, conditions and requirements from all departments and agencies with jurisdiction over the project, shall be completed prior to granting of a Certificate of Final Occupancy by the County Building Official, which, upon granting, authorizes all use permit activities to commence.

  • RECOMMENDED CONDITION: (G1) Prior to obtaining the Certificate of Final Occupancy, construct and install the pathway and other Tract A open space amenities.

  • SFDPH approval is required prior to SFDBI issuance of a Certificate of Final Occupancy or Completion.An initial cross connection test performed by a certified cross connection control specialist is required prior to the operation of the non-potable water system.

Related to Final Occupancy

  • Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.

  • Transient occupancy means occupancy in transient lodging that has all of the following

  • Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.

  • Owner-occupied means property that is the principal

  • Certificate of Occupancy means a document issued by the Town certifying that the building or structure, or portion thereof, complies with the approved construction documents that have been submitted to, and approved by the Town, and indicating that the building or structure, or portion thereof, is in a condition suitable for occupancy.

  • Child-occupied facility means a building or portion of a building constructed prior to 1978, visited regularly by the same child, age six years or younger on at least two different days within any week (Sunday through Saturday period), provided that each day’s visit lasts at least three hours and the combined weekly visit lasts at least six hours, and the combined annual visits last at least 60 hours. Child-occupied facilities may include, but are not limited to, day-care centers, preschools and kindergarten classrooms.

  • Permitted Occupier means if used in the Agreement, any person who is licensed or permitted by the Landlord to reside at the Property together with the Tenant and who does so as a rent free licensee of the Tenant.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Occupancy means the use or intended use of a building or part thereof for the shelter or support of persons, animals or property.

  • Authorized occupant means a person entitled to occupy a dwelling unit with the consent of the

  • bicycle parking space – occupant means an area that is equipped with a bicycle rack, locker or bicycle stacker for the purpose of parking and securing bicycles, and:

  • Date of occurrence in these Regulations means the date of contract signing, date of payment, dates of boards of directors resolutions, or other date that can confirm the counterparty and monetary amount of the transaction, whichever date is earlier.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Home occupation means an occupation permitted in a dwelling unit and which:

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).

  • Occupancy Rate means, with respect to a Property at any time, the ratio, expressed as a percentage, of (a) the number of units in the case of an multifamily Property or square feet in the case of any other Property leased to tenants that are not affiliated with the Borrower pursuant to binding leases to (b) the aggregate number of units or square feet, as applicable, of such Property.

  • Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.