First Outside Date definition

First Outside Date shall have the meaning set forth in Section 7.1(b).
Sample 1Sample 2Sample 3
First Outside Date. Section 7.8(e)
Sample 1Sample 2
First Outside Date means July 31, 2012.
Sample 1Sample 2

Examples of First Outside Date in a sentence

  • This Agreement shall terminate if the Phase 1 Closing does not take place by the First Outside Date, the Phase 2 Closing does not take place by the Second Outside Date, or the Phase 3 Closing does not take place by the Third Outside Date.

  • In the event the Premises are not delivered to Tenant with all Base Building Work substantially completed by the later of November 1, 2014, or the date that is 240 days following Landlord’s receipt of the Phase 2 Base Building Approvals (the “First Outside Date”), Tenant will be granted a rent credit in the amount of one (1) day of abated Base Rent for every one (1) day of delivery after the First Outside Date.

  • In the event Landlord fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before November 1, 2015 ("First Outside Date") as such First Outside Date shall be extended due to Force Majeure delays and Tenant Delays, Tenant will be entitled to one day of free Monthly Base Rent, to be applied after the Term Commencement Date, for each day after such First Outside Date that the Premises are not delivered to Tenant as required hereunder.

  • The “First Outside Date” shall mean the date thirty (30) days after the Estimated Substantial Completion Date, provided, however, that the First Outside Date shall be extended by the length of any delays in Landlord’s Work arising from Force Majeure, Tenant Delays and/or Existing Tenant Delays.

  • If Landlord has not Substantially Completed Landlord’s Work on or before the First Outside Date (defined below), Tenant shall be entitled to a credit against Tenant’s obligation to pay Base Rent following the Phase II Rent Commencement Date equal to one (1) day for each day between the First Outside Date and the earlier to occur of the Second Outside Date (defined below) or the Substantial Completion of Landlord’s Work.

  • AdaptationThe process of adjustment to actual or expected climate and its effects.

  • The First Outside Date and the Second Outside Date shall each be postponed by one (1) day for each day that the Commencement Date has not occurred by reason of an Unavoidable Delay (as hereinafter defined); provided, however, that the postponement of the Second Outside Date by reason of an Unavoidable Delay shall not exceed twelve (12) months.

  • The “Second Outside Date” shall mean the date that is thirty (30) days after the First Outside Date.

  • The First Outside Date and the Second Outside Date shall each be extended one (1) day for each day of delay in the occurrence of the Commencement Date that results from Tenant Delays and/or Force Majeure Delays; provided, however, with respect the Second Outside Date only, such day for day extension on account of Force Majeure Delays shall not exceed ninety (90) days in the aggregate.

  • Notwithstanding the foregoing, the 20th Floor First Outside Date and the 20th Floor Second Outside Date shall each be extended by one day for each day that the completion of the Building Work which is applicable to such space is delayed due to any of the causes set forth in Article 21A of this Lease or due to any act or omission of Tenant, its agents, employees or contractors.


More Definitions of First Outside Date

First Outside Date has the meaning set forth in Section 2.2.
Sample 1
First Outside Date means the sixtieth (60th) day following the date which is the later to occur of: (a) the date upon which all prepaid Rent and the Letter of Credit are delivered to Landlord, and (b) the Scheduled Commencement Date (i.e. November 1, 2008); provided, however, the First Outside Date shall be postponed by the number of days Landlord’s delivery to Tenant of possession of the Premises with the Landlord’s Work Substantially Completed (calculated as described in clause (ii) (A) of the first grammatical paragraph of this Section 2(a)) is delayed due to events of Force Majeure (as defined in Paragraph 12(f) below). The credit provided in this grammatical paragraph shall be the sole remedy of Tenant for any delay by Landlord in delivering possession of the Premises to Tenant beyond the First Outside Date, except as set forth in the immediately following grammatical paragraph.
Sample 1
First Outside Date. (Article 1F(i)) If Landlord fails to substantially complete Landlord’s Work on or before November 14, 2008,3 then Tenant shall be entitled to a rent credit against fixed annual rent (without electricity) in the amount of $12,516.47 per day for each day after November 14, 2008 that Landlord fails to substantially complete Landlord’s Work.
Sample 1
First Outside Date means the date thirty (30) days after the Estimated Substantial Completion Date, provided, however, that the First Outside Date shall be extended by the length of any delays in Landlord’s Work arising from Force Majeure, Tenant Delays and/or Existing Tenant Delays. Furthermore, if Landlord has not Substantially Completed Landlord’s Work on or before the Second Outside Date (defined below), Tenant shall be entitled to a credit against Tenant’s obligation to pay Base Rent following the Phase II Rent Commencement Date equal to two (2) days for each day between the Second Outside Date and the Substantial Completion of Landlord’s Work. The “Second Outside Date” shall mean the date sixty (60) days after the Estimated Substantial Completion Date; provided, however, that the Second Outside Date shall be extended by the length of any delays in Landlord’s Work arising from Force Majeure, Tenant Delays and/or Existing Tenant Delays. The provisions set forth in this Section 8.1(H) shall be Tenant’s sole remedy for any delay in the Substantial Completion of Landlord’s Work.
Sample 1

Related to First Outside Date

  • Outside Date has the meaning set forth in Section 8.1(b).

  • Extension Deadline means, with respect to a letter of credit, the Cutoff Time on the Business Day preceding the day on which the letter of credit expires.

  • Outside Closing Date means the date which is 365 days after the earlier of the Firm Closing Date; or Second Tentative Closing Date; or such other date as may be mutually agreed upon in accordance with section 4. “Property” or “home” means the home including lands being acquired by the Purchaser from the Vendor. “Purchaser’s Termination Period” means the 30-day period during which the Purchaser may terminate the Purchase Agreement for delay, in accordance with paragraph 10(b).

  • Extension Minimum Condition means a condition to consummating any Extension that a minimum amount (to be determined and specified in the relevant Extension Request, in the Borrower’s sole discretion) of any or all applicable Classes be submitted for Extension.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Second Extension Period means the period of one (1) Contract Year commencing immediately after the end of the First Extension Period.

  • Opt-Out Deadline means the deadline set by the Court for the timely submission of requests by Settlement Class Members to be excluded from the Settlement Class.

  • Increased Facility Closing Date any Business Day designated as such in an Increased Facility Activation Notice.

  • Non-Extension Notice Date has the meaning specified in Section 2.03(b)(iii).

  • First Extension Period means the period of one (1) Contract Year commencing immediately after the conclusion of the Initial Exploration Period.

  • Second Draw Period is the period commencing on December 1, 2015 and ending on the earlier of (i) January 31, 2016 and (ii) the occurrence of an Event of Default; provided, however, that the Second Draw Period shall not commence if on December 1, 2015, an Event of Default has occurred and is continuing.

  • Existing Commitment Termination Date as defined in Section 2.12(a).

  • Offer Closing Date has the meaning set forth in Section 1.01(f).

  • L/C Expiration Date means the day that is thirty days prior to the Maturity Date then in effect (or, if such day is not a Business Day, the next preceding Business Day).

  • IPO Closing Date means the closing date of the IPO.

  • First Amendment Closing Date has the meaning assigned to such term in the First Amendment.

  • Term Commencement Date shall be the later of (i) November 1, 2006 or (ii) the date on which Landlord’s Work is Substantially Complete (or the date on which Landlord’s Work would have been Substantially Complete absent Tenant Delay or Force Majeure (as defined below)); provided, however, that if the Term Commencement Date is not the first day of a calendar month, then the first lease year shall be extended through the last day of the calendar month in which the first 12-month period expires, and Rent for the additional period at the end of the first lease year shall be payable at the rate for the 12th month of the Term. “Force Majeure” means accident; breakage; repair; governmental regulation, moratorium or other governmental action. The “Term Expiration Date” shall be the day immediately preceding the seventh (7th) anniversary of the Term Commencement Date, provided that if such preceding day is not the last day of a calendar month, then the Term Expiration Date shall be the last date of the calendar month in which such preceding day occurs. Landlord and Tenant shall each execute and deliver to the other written acknowledgment of the actual Term Commencement Date and the Term Expiration Date when such are established, and shall attach it to this Lease as Exhibit B. Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.

  • Loan Commencement Date means, with respect to each Growth Capital Loan: (a) the first day of the first full calendar month following the Borrowing Date of such Loan if such Borrowing Date is not the first day of a month; or (b) the same day as the Borrowing Date if the Borrowing Date is the first day of a month.

  • Lock-up Period means the period beginning on the date hereof and continuing through the close of trading on the date that is 90 days after the date of the Prospectus (as defined in the Underwriting Agreement).

  • Offer Commencement Date means the date on which Purchaser commences the Offer, within the meaning of Rule 14d-2 under the Exchange Act.

  • Additional Closing Date has the meaning set forth in Section 3.

  • Revolving Commitment Termination Date means the earliest to occur of (i) the fifth anniversary of the Closing Date, (ii) the date the Revolving Commitments are permanently reduced to zero pursuant to Section 2.13(b) or 2.14, and (iii) the date of the termination of the Revolving Commitments pursuant to Section 8.1.

  • Second Amendment Closing Date has the meaning assigned to such term in the Second Amendment.

  • Third Amendment Closing Date has the meaning assigned to such term in the Third Amendment.

  • Second Extended Maturity Date has the meaning set forth in Section 2.10.

  • Extension Determination Date means, in respect of a Series of Covered Bonds, the date falling two Business Days after the expiry of seven days from (and including) the Final Maturity Date of such Covered Bonds.