Improvements Completion Date definition

Improvements Completion Date means the deadline for Completion of each element of the Improvements as set forth on the Approved Construction Schedule.
Sample 1Sample 2
Improvements Completion Date has the meaning set forth in Section 6.1 hereof.
Sample 1Sample 2Sample 3
Improvements Completion Date means the date on which the City Engineer certifies in writing that the Authorized Improvements have been constructed in substantial compliance with the approved plans and specifications for such improvements and are ready to be accepted by the City.
Sample 1

Examples of Improvements Completion Date in a sentence

  • Until the Infrastructure Improvements Completion Date, the membership interests in RCP may not be transferred to a third party other than the University of Kansas or Kansas Athletics, Inc.

  • Subsequently, the spectral region from 1626 - 1676 cm-1 (the amide I band position associated with cellular proteins) was integrated to produce a raw intensity map of the imaged area.

  • The City acknowledges that except for any express warranties or representations made by RCP in this Agreement or in a document hereafter executed by RCP and delivered to the City, RCP is not now, and on the Infrastructure Improvements Completion Date will not be, making any express or implied representations as to the Infrastructure Improvements and the condition or continuing performance thereof.

  • After Closing, if the Recreation Center Contractor or any of its subcontractors damage any of the Infrastructure Improvements or the work in progress related to Infrastructure Improvements of RCP or RCP’s contractor and its subcontractors and materialmen, whether on before or after the Infrastructure Improvements Completion Date, then the City and the Recreation Center Contractor are responsible for such damages.

  • The Parties agree that to the extent, if any, that the City does not receive the sum referred to in Section 12.02(b) above by the thirtieth (30th) day after the Infrastructure Improvements Completion Date, the Infrastructure Payment will be reduced in accordance with Section 11.01.

  • In the event that any portion of the Improvement Allowance remains unused on the Leasehold Improvements Completion Date, Tenant shall have the option to have such unused amounts applied to Base Rent first due under this Lease Agreement.

  • In the event Tenant fails to deliver written notice of its election of either (y) or (z) above prior to the Leasehold Improvements Completion Date, Tenant shall be deemed to have elected (y) above and Tenant shall make payment of such excess amount within fifteen (15) days after receipt from Landlord of an invoice setting forth such excess amount.

  • In the event of Tenant Delay, the Leasehold Improvements Completion Date shall be accelerated by the number of days equal to Tenant Delay.

  • Tenant covenants that it shall not cause Tenant Delay with respect to the Leasehold Improvements Completion Date and shall timely respond to any request for approval in accordance with Landlord’s Construction Guidelines, from time to time promulgated.

  • The Small Tenant Work Fee with respect to the Tenant Improvements for each such tenant shall be due and payable in one lump sum on the Tenant Improvements Completion Date for such Tenant Improvements.


More Definitions of Improvements Completion Date

Improvements Completion Date means the deadline for completion of each element of construction, development, renovation and rehabilitation of the Improvements as set forth on the Approved Construction Schedule, which shall not be later than October 1, 2004.
Sample 1

Related to Improvements Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Construction Work means any work in connection with⎯

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.