Lease Line Schedule definition

Lease Line Schedule means a Lease Line Schedule in the form of EXHIBIT A-L or EXHIBIT A-2 signed by Lessor and Lessee and incorporating by reference the terms and provisions of this Master Lease.
Sample 1Sample 2

Examples of Lease Line Schedule in a sentence

  • If Lessee exercises the option to renew this Lease, such renewal shall be upon the terms and conditions of this Master Lease and the applicable Lease Line Schedule, for a rental period and rental amount to be agreed upon by Lessee and Lessor.

  • Lessor leases to Lessee and Lessee leases from Lessor the personal property described in each Equipment Schedule executed pursuant hereto, subject to the terms and conditions of this Master Equipment Lease Agreement ("Master Lease") and the applicable Lease Line Schedule (defined below).

  • Lessee shall pay a late charge on any rent payments or other sums due hereunder which are past due, in the amount specified in the Lease Line Schedule, payable on demand.

  • Any notices or demands required or permitted hereunder shall be given to the parties in writing and by personal delivery, regular or certified mail, facsimile or telegram at the address set forth in the Lease Line Schedule or to such other address as the parties may hereafter substitute by written notice given in the manner prescribed in this Section.

  • In addition, interest shall accrue daily at the "Default Rate" (as defined in the Lease Line Schedule), or if such rate exceeds the maximum rate allowed by law, then at such maximum rate, and shall be payable on demand.

  • The Lease may only be terminated as expressly provided in this Section, in the applicable Lease Line Schedule or in the applicable Equipment Schedule.

  • If a Notice of Election is not submitted by Lessee to Lessor during the "Advance Notice Period" (as defined in the Lease Line Schedule), then the Lease Term or any renewal Term will be automatically extended for an additional period equal to the "Automatic Extension Period" (as defined in the Lease Line Schedule).

  • Capitalized terms used, but not defined, in this Master Lease have the meanings given to such terms in the applicable Lease Line Schedule or Equipment Schedule, as the case may be.

  • The purchase price shall be the Equipment's then fair market value ("FMV") or as may be otherwise provided in a particular Lease Line Schedule.

  • The Interim Rent payment for the Interim Period shall accrue at the "Interim Rate" (as defined in the Lease Line Schedule) and shall be due and payable in full on the Commencement Date.

Related to Lease Line Schedule

  • Base Lease means the Base Lease Agreement delivered concurrently with this Lease between the Company and the Issuer.

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • Reduced leave schedule means a leave schedule that reduces the usual number of hours per workweek, or hours per workday, of an employee.

  • Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).

  • Built-Up Area and/or “Covered Area” in relation to a Flat shall mean the floor area of that Flat including the area of balconies and terraces, if any attached thereto, and also the thickness of the walls (external or internal) and the columns and pillars therein Provided That if any wall, column or pillar be common between two Flats, then one-half of the area under such wall column or pillar shall be included in the built-up area of each such Flat.

  • Building Square Footage or "BSF" means the square footage of assessable internal living space of a Unit, exclusive of any carports, walkways, garages, overhangs, patios, enclosed patios, detached accessory structure, other structures not used as living space, or any other square footage excluded under Government Code Section 65995 as determined by reference to the Building Permit for such Unit.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements in the form of Exhibit D attached hereto.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Parking space leasing data means the following government data on an application for, or lease of, a parking space: residence address, home telephone number, beginning and ending work hours, place of employment, location of parking space, and work telephone number.

  • Leased Aircraft Has the meaning specified in the third recital to this Trust Supplement.

  • Rentable Area of Premises on Page 1 of the Lease shall be deleted in their entirety and replaced with the following:

  • Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.

  • Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.

  • Existing Lease shall have the meaning assigned thereto in Section 10.7.

  • Original Lease shall have the meaning given such term in the recitals to this Agreement.

  • Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • building line means a rear space, side space or street front space;

  • Rentable Area when applied to the Premises, is that area equal to the usable area of the Premises, plus an equitable allocation of Rentable Area within the Building that is not then utilized or expected to be utilized as usable area, including that portion of the Building devoted to corridors, equipment rooms, restrooms, elevator lobby, atrium and mailroom.

  • Time Schedule means the Time Schedule for final completion of the Works or Mechanical Completion of the Plant(s)/Unit(s), as the case may be, incorporated in the Contract or as may be extended by the OWNER or Engineer- in-Charge pursuant to the provisions hereof and shall include interim time schedules set up for achieving interim/phase-wise/stage-wise progress/completion/testing/commissioning/ handing over, as may be prescribed by the OWNER/Engineer-in-Charge, within the overall Time Schedule as originally envisaged or as extended.

  • Parking Space The County shall attempt to provide adequate free parking facilities for employees within a reasonable distance of their work locations.

  • Facility Lease means a lease or master lease with respect to any Real Property Asset owned or ground leased by any of the Consolidated Parties as lessor, to a third party Tenant, which, in the reasonable judgment of the Administrative Agent, is a triple net lease such that such Tenant is required to pay all taxes, utilities, insurance, maintenance, casualty insurance payments and other expenses with respect to the subject Real Property Asset (whether in the form of reimbursements or additional rent) in addition to the base rental payments required thereunder such that net operating income to the applicable Consolidated Party for such Real Property Asset (before non-cash items) equals the base rent paid thereunder; provided, that each such lease or master lease shall be in form and substance reasonably satisfactory to the Administrative Agent.

  • Leased space means a self−service storage unit or a space located within a self−service storage facility that a lessee is enti- tled to use for the storage of personal property on a self−service basis pursuant to a rental agreement and that is not rented or pro- vided to the lessee in conjunction with property for residential use by the lessee.