RESPONSIBILITY FOR CLAIMS AND LIABILITY. The Engineer agrees to save harmless the Local Agency, MoDOT and FHWA from all claims and liability due to his negligent acts or the negligent acts of his employees, agents or subcontractors.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. It is hereby stipulated and agreed between the parties that, with respect to any claim or action brought by a third party and arising out of the activities described in this IGA or stems from any matter arising out of any actual or alleged infringement of any patent, trademark, copyright, or service xxxx, or other actual or alleged unfair competition disparagement of product or service, or other tort or any type whatsoever, or any actual or alleged violation of trade regulations, each party shall only be liable for payment of that portion of any and all liability, costs, expenses, demands, settlements, or judgments resulting from the negligence actions or omissions of its own agents, officers, and employees. Either Party may self-fund its obligations under this IGA. However, nothing herein shall be construed as a waiver of any Party’s sovereign immunity or the immunities available to the officials, officers and employees of the Parties. To the extent allowed by law, the CITY shall ensure that any contractor retained or selected by the CITY to provide services related to the UTILITIES RELOCATOIN work contemplated in this IGA shall agree to indemnify and hold harmless the COUTNY as well as its commissioners, officers, officials, employees, and agents, from and against any and all loss and/or expense which it or any of them may suffer or pay as a result of claims or suits due to, because of, or arising out of any and all such injuries, deaths and/or damage, arising out of the UTILITIES RELOCATION work irrespective of the COUNTY’s negligence (except that no Party shall be indemnified for their own sole negligence). Any contractor retained by the CITY, if requested, shall assume and defend at the contractor’s own expense, any suit, action or other legal proceedings arising therefrom in which the COUNTY, and/or its commissioners, officers, officials, employees, and agents, are named as a party, and the contractor hereby agrees to satisfy, pay, and cause to be discharged of record any judgment which may be rendered against the COUNTY and/or its commissioners, officers, officials, employees, and agents, arising therefrom. The CITY shall ensure that the provisions of this Article are included in all contracts and subcontracts.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. The AGENCY shall be responsible for all damages to life, body, and property due to the activities of the AGENCY and its agents or employees, in connection with their services under this AGREEMENT, and agrees to pay costs, charges, expenses or incurred liabilities to said agents or employees arising hereunder. The AGENCY specifically agrees that its agents or employees shall possess the experience, knowledge, and character to qualify them individually for the particular duties they perform. Further, it is understood and agreed that the AGENCY shall indemnify and save and hold harmless the DEPARTMENT, its officers, employees, the State of Iowa, and the Federal Government for all claims, suits, actions, damages, and costs, whether real or asserted, arising out of any negligent act or omission, whether real or asserted, on the part of the AGENCY, its officers, agents and employees or subcontractors which may result from their operations in connection with the work to be performed or losses due to performance of equipment purchased under this project.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. The CONSULTANT shall be responsible for any and all damages to properties or persons caused by its employees, subcontractors, or agents, and shall hold harmless the CITY, its officers, agents and employees from all suits, claims, actions or damages of any nature whatsoever to the extent found to be resulting from the CONSULTANT, its subcontracts, or agent in the negligent performance or non-performance of work under this Agreement. These indemnities shall not be limited by reason of the listing of any insurance coverage.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. The SPONSOR shall, to the extent permitted by law, be responsible for any and all damages to property or persons and shall save harmless the DEPARTMENT, its officers, agents and employees from all suits, claims, actions or damages of any nature whatsoever resulting from the negligence of the SPONSOR in the performance of the work under this Agreement. It is understood by the SPONSOR that claims, damages, losses, and expenses may include monetary claims made by the construction contractor for the PROJECT, and its related facilities, that are a result of the SPONSOR's negligence or improper representation in the plans. The SPONSOR shall ensure that the provisions of this Article are included in all contracts and subcontracts. These indemnities shall not be limited by reason of any insurance coverage held by the SPONSOR or the SPONSOR's contractors or subcontractors.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. 4.10 Current and Former Agency Employees (Conflicts of Interest) 4.11 Suspension of Work 4.12 Termination of Agreement
RESPONSIBILITY FOR CLAIMS AND LIABILITY. 4.10.1 The Consultant shall defend, indemnify and save harmless the Iowa Department of Transportation, the State of Iowa, its agencies, agents, employees and assignees and the Federal Government from all claims and liabilities due to design error, omission or negligent act of the Consultant, its members, agents, stockholders, employees, or subconsultants in connection with performance of this Agreement.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. 4.9.1 The Consultant agrees to indemnify and hold the Owner, the State of Iowa, the Iowa DOT, their agents, employees, representatives, assigns and successors harmless for any and all liabilities, costs, demands, losses, claims, damages, expenses, or attorneys' fees, including any stipulated damages or penalties, which may be suffered by the Owner as the result of third-party claims to the extent caused by, arising out of, or resulting from the negligence, negligent errors or omissions, willfully wrongful misconduct, or breach of any covenant or warranty in this Agreement of or by the Consultant or any of its employees, agents, directors, officers, subcontractors or subconsultants, in connection with this Agreement.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. The LOCAL GOVERNMENT shall, to the extent permitted by law, be responsible for any and all damages to property or persons and shall indemnify and save harmless the DEPARTMENT, its officers, agents and employees from all suits, claims, actions or damages of any nature whatsoever resulting from the negligence of the LOCAL GOVERNMENT in the performance of the work under this Agreement. It is understood by the LOCAL GOVERNMENT that claims, damages, losses, and expenses may include monetary claims made by the construction contractor for the PROJECT, and its related facilities, that are a result of the LOCAL GOVERNMENT's negligence or improper representation in the plans. The LOCAL GOVERNMENT shall ensure that all provisions of this Article are included in all contracts and subcontracts. These indemnities shall not be limited by reason of any insurance coverage held by the LOCAL GOVERNMENT or the LOCAL GOVERNMENT's contractors or subcontractors as allowed by law.
RESPONSIBILITY FOR CLAIMS AND LIABILITY. To the extent allowed by law, SPONSOR shall be responsible for any and all damages to property or persons and shall save harmless the DEPARTMENT, its officers, agents, and employees, from all suits, claims, actions, or damages of any nature whatsoever resulting from the negligence of the SPONSOR under this AGREEMENT. To the extent allowed by law, the SPONSOR hereby indemnifies and agrees to hold harmless the DEPARTMENT from suits, claims, actions, or damages of any nature whatsoever by any person, firm, corporation, or governmental body resulting from any defective equipment or material purchased by the SPONSOR and reimbursed under this AGREEMENT or from the installation and operation thereof or from operation of equipment and materials already owned by the SPONSOR.
