Utility Delay definition

Utility Delay means a delay to the Phase 2 Work arising out of a delay by a Utility Owner in performing Utility Work which the Utility Owner has elected to perform under a Utility Relocation Agreement.
Sample 1Sample 2Sample 3
Utility Delay means:
Sample 1Sample 2Sample 3
Utility Delay means a schedule delay that impairs the ability of the Purchaser to execute the Interconnection Agreement for the Project with the New York Independent System Operator and/or the Utility which delay is directly attributable to either: (a) inability of Purchaser, after diligent efforts, to reach agreement with the Utility, caused by the Utility’s unreasonable delays, as determined by Seller; or (b) failure by the Utility to meet any time parameters for performance by such Utility which are set forth in the OATT.
Sample 1Sample 2

Examples of Utility Delay in a sentence

  • The Purchaser shall not be entitled to an extension of the IA Drop Dead Date unless it continues to adhere to the requirements of this Section 6.03 during any Utility Delay.

Related to Utility Delay

  • Tenant Delay means any actual delay in the Substantial Completion of the Initial Improvements specified in a written notice to Tenant delivered by Landlord within one (1) business day after the occurrence of such delay (a “Tenant Delay Notice”) due to (a) any change by Tenant to the Scope of Work, (b) any material specification by Tenant of materials or installations which were not included in the Scope of Work or the Space Plan and which, because of long lead-time requirements or shortage of supply/availability, will actually delay Substantial Completion of the Initial Improvements, (c) any other delay otherwise caused by Tenant or any Tenant Party being in possession of the Premises or not performing any express requirement of Tenant under the terms of this Lease after Landlord’s written request therefor or any interference by Tenant or any Tenant Party with Landlord’s or its contractor’s, subcontractor’s, employee’s or agent’s construction activities in connection with the Project. For purposes of determining the Commencement Date, the Substantial Completion date shall be accelerated by one (1) day for each day of Tenant Delay specified in a Tenant Delay Notice. As soon as the Initial Improvements have been substantially completed, subject to any remaining items which do not materially interfere with or prevent Tenant from occupying and using the Premises for the permitted uses (i.e., punch-list items), and a certificate of occupancy or its equivalent for the Premises has been obtained (“Substantial Completion”), Landlord shall notify Tenant in writing that the Premises are ready for occupancy. Within ten (10) days thereafter, Tenant shall submit to Landlord in writing a punch list of items needing completion or correction. Landlord shall use commercially reasonable efforts to complete such items within thirty (30) days after it receives such notice. Landlord shall allow changes to the Scope of Work and the Space Plan. If Tenant requests any change to the Scope of Work or the Space Plan, Tenant shall submit a written change order to Landlord and Landlord shall promptly thereafter deliver to Tenant a written notice specifying all additional costs in designing and constructing the Initial Improvements as a result of such change order (taking into account any cost savings attributable to such change order or prior change orders) and Tenant shall either pay to Landlord such specified additional costs or revoke such change order.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Utility Costs means utility and home energy costs related to the occupancy of rental property (e.g. electricity, gas, water and sewer, trash removal, and energy costs (such as fuel oil)) that are separately-stated charges. Utility Costs do not include telecommunication services (e.g. telephone, cable, and internet services).