Acceptance of Leased Premises On or before the Possession Date, Tenant and Landlord shall each execute the letter agreement in the form attached hereto as Exhibit E (the “Letter Agreement”). By its execution of the Letter Agreement or occupancy of the Leased Premises, Tenant shall be deemed to represent and certify that it has examined the Leased Premises and that it thereby accepts the Leased Premises in its condition at the time, except for the list of defects and/or omissions identified in writing prior to the Possession Date (the “Punch-List”) and latent defects, but subject, in all cases, to Landlord’s repair, maintenance and replacement obligations set forth in this Lease and to the warranty related to the Tenant Improvements, as provided in the Work Letter Agreement. After the notice provided in Section 3.03 and prior to the Possession Date, the parties shall meet in the Leased Premises to establish the Punch-List. Landlord shall review the Punch-List items with Tenant and correct all undisputed Punch- List items within a reasonable time, not to exceed thirty (30) days after receipt of the Punch- List; provided that, if any Punch-List items cannot be corrected within such thirty (30) day period despite reasonable diligence by Landlord, then, so long as Landlord commences correction of such Punch-List items within such thirty (30) day period and diligently pursues such correction to completion, no default by Landlord shall be deemed to have occurred. Punch-List items for completion taking longer than six (6) months to complete (and not otherwise the result of Force Majeure, Tenant Delay, or the COVID-19 Condition) shall trigger a day for day prorated Minimum Monthly Rent abatement. The Tenant Improvements shall be subject to a two (2) year warranty, from the Possession Date, with regard to materials, design and workmanship, as provided in more detail in the Work Letter Agreement. Tenant shall reasonably cooperate with Landlord in providing required information as needed for Landlord to pursue vendor warranties on a timely basis, as requested in writing by Landlord. Landlord will pursue any valid warranty claims against its contractor beyond the two (2) year warranty provided that any expenses incurred and/or any recovery obtained shall be treated as either additional Operating Costs or an offset to Operating Costs under Section 5.03(a).
Acceptance of Order We may in our sole discretion accept an Order in whole or in part. An Order is accepted by us through our trading platform.
Acceptance of the Terms of Use These terms of use are entered into by and between you and Tribal Convenience Store Association ("Company", "we" or "us"). The following terms and conditions (these "Terms of Use") govern your access to and use of the Company’s website, xxxx://xxx.xxxxxxxxxxxxx.xxx, including any content, functionality and services offered on or through the website (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use. If you do not want to agree to these Terms of Use, you must not access or use the Website. This Website is offered and available only to users who are 18 years of age or older, and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.
Acceptance of Agreement This Agreement shall not be considered accepted, approved or otherwise effective until the statutorily required approvals and certifications have been given.
Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.
Acceptance of Premises Lessee hereby acknowledges: (a) that it has been advised by the Broker(s) to satisfy itself with respect to the condition of the Premises (including but not limited to the electrical and fire sprinkler systems, security, environmental aspects, seismic and earthquake requirements, and compliance with the Americans with Disabilities Act and applicable zoning, municipal, county, state and federal laws, ordinances and regulations and any covenants or restrictions of record (collectively, "Applicable Laws") and the present and future suitability of the Premises for Lessee's intended use; (b) that Lessee has made such investigation as it deems necessary with reference to such matters, is satisfied with reference thereto, and assumes all responsibility therefore as the same relate to Lessee's occupancy of the Premises and/or the terms of this Lease; and (c) that neither Lessor, nor any of Lessor's agents, has made any oral or written representations or warranties with respect to said matters other than as set forth in this Lease.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:
1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or
2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
Acceptance of Deliverables The State’s Project Manager shall be responsible for the sign-off acceptance of all Deliverables required and performed/submitted pursuant to this Agreement. Upon successful completion of a Deliverable, Contractor shall provide the State’s Project Manager with a completed Acceptance and Signoff Form (Exhibit E). The State’s Project Manager will apply the standards established in Exhibit D and the acceptance criteria set forth in subparagraph B of this article, as appropriate, to determine the acceptability of the Deliverable provided by Contractor. If the State’s Project Manager rejects the Deliverable, the parties agree to any dispute(s) resulting from such rejection(s) will be resolved as set forth in this article. Acceptance Criteria for Deliverables (“Criteria”) provided by Contractor pursuant to this Agreement include: Timeliness: The Work was provided on time; according to schedule; Completeness: The Deliverable contained all of the, Data, Materials, and features required by the Agreement; and Technical accuracy: The Deliverable complied with the standards of this Agreement, or, if this Agreement lacks a standard for provision of the Work, the currently generally accepted industry standard. Contractor shall provide the Deliverable to the State, in accordance with direction from the Project Manager and as provided for in Exhibit D. The State shall accept the Deliverable, provided that Contractor has delivered the Deliverable in accordance with the Criteria. The State’s Project Manager shall assign the Acceptance and Signoff Form to notify Contractor of the Deliverable’s acceptability. If the State rejects the Deliverable provided, the State’s Project Manager shall submit to Contractor’s Project Manager a written rejection describing in detail the failure of the Deliverable as measured against the Criteria. If the State rejects the Deliverable, then Contractor shall have a period of ten (10) Business Days from receipt of the Notice of rejection to correct the stated failure(s) to conform to the Criteria.
Acceptance of Rent 7.1 Acceptance of Rent by the Landlord or the Landlord’s Agent shall be at all times without prejudice to and shall not be a waiver of the rights and remedies of the Landlord in respect of any breach of the Tenant’s agreements of stipulations contained in this Agreement; and any Rent paid by any third party will be accepted from that person as the agent of the Tenant only and will not confer on the third party any rights as the Tenant.
