Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit F Resume Self-Certification Form Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit G Contractor Selection Justification Form Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: _ Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: _ Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit H Contractor Performance Survey Note: This is an example of the questions contained in the Contractor Performance Survey. The actual survey will be provided in electronic form. Customers shall complete this Contractor Performance Survey for each Contractor on a quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated the Scope of Work. Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following: Quality of Service
Liability for Failure to Stop Payment of Preauthorized Transfer If you order us to stop one of these payments 3 business days or more before the transfer is scheduled, and we do not do so, we will be liable for your losses or damages.
ONLY No response If proposing on Part 2, the vendor must download the Vendor Agreement from the attachment tab, fill in the requested information and upload the completed agreement. DO NOT UPLOAD encrypted or password protected files.
OUR RESPONSIBILITY FOR LOSS OR DAMAGE SUFFERED BY YOU 14.1 We are responsible to you for foreseeable loss and damage caused by us. If we fail to comply with this Agreement, we are responsible for loss or damage you suffer that is a foreseeable result of our breaking this Agreement or our failure to use reasonable care and skill, but we are not responsible for any loss or damage that is not foreseeable. Loss or damage is foreseeable if either it is obvious that it will happen, or if, at the time the Agreement is made, both we and you knew it might happen. We are not responsible for any loss or damage you suffer which is a result of you breaking this Agreement or you acting fraudulently.
RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY The Respondent shall be liable for all damages to government-owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance pursuant to the Contract. The Respondent shall notify the City of Xxxxxx Procurement Manager in writing of any such damage within one (1) calendar day.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Lobbying Activities - Standard Form - LLL No response Do not upload this form unless Vendor has reportable lobbying activities. There are Attributes entitled, “2 CFR Part 200 or Federal Provision - Xxxx Anti-Lobbying Amendment – Continued.” Properly respond to those Attributes and only upload this form if applicable/instructed. If upload is required based on your response to those Attributes, the Disclosure of Lobbying Activities – Standard Form - LLL must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded to this location.
Vendor Logo (Supplemental Vendor Information Only) No response Optional. If Vendor desires that their logo be displayed on their public TIPS profile for TIPS and TIPS Member viewing, Vendor may upload that logo at this location. These supplemental documents shall not be considered part of the TIPS Contract. Rather, they are Vendor Supplemental Information for marketing and informational purposes only. Bid Attributes Disadvantaged/Minority/Women Business & Federal HUBZone Some participating public entities are required to seek Disadvantaged/Minority/Women Business & Federal HUBZone ("D/M/WBE/Federal HUBZone") vendors. Does Vendor certify that their entity is a D/M/WBE/Federal HUBZone vendor? If you respond "Yes," you must upload current certification proof in the appropriate "Response Attachments" location. NO Historically Underutilized Business (HUB) Some participating public entities are required to seek Historically Underutilized Business (HUB) vendors as defined by the Texas Comptroller of Public Accounts Statewide HUB Program. Does Vendor certify that their entity is a HUB vendor? If you respond "Yes," you must upload current certification proof in the appropriate "Response Attachments" location. No National Coverage Can the Vendor provide its proposed goods and services to all 50 US States? Yes
LIABILITY FOR UNAUTHORIZED USE-LOST/STOLEN CARD NOTIFICATION You agree to notify Credit Union immediately, orally or in writing at Florida Credit Union, X.X. Xxx 0000, Xxxxxxxxxxx, XX 00000 or telephone (000) 000-0000 twenty four
