General Responsibilities of the Parties 1. The Parties will work together in a spirit of cooperation and partnership, with the responsibilities and accountabilities set out in this Agreement, to implement the Programme Documents in full in a timely, efficient, and effective, manner.
2. The Parties agree to carry out their respective responsibilities in accordance with the provisions of this Agreement, including the Programme Documents.
3. The Parties shall keep each other informed of all relevant activities pertaining to the implementation of the Programme Documents, and shall hold consultations when either Party considers it appropriate, including any circumstance that may affect the achievement of the results of the Programme and the Programme Documents.
4. The Parties shall fulfill their commitments with the fullest regard for the terms and conditions of this Agreement and the principles of the United Nations.
Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services:
3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff.
3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote.
3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer.
3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them.
3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances.
3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market.
3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff.
3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services.
3.9 Contractor shall be responsible for all costs associated with the administration of this Contract.
3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer.
3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc.
3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.
Mutual Responsibilities It is recognized by this Agreement to be the duty of the Company to explain fully the terms of this Agreement to all its officers, foremen and others engaged in a supervisory capacity and it is recognized to be the duty of the Union to explain fully to its members, its and their responsibilities and obligations under this Agreement.
Limitation on Responsibilities of Agent Agent shall not be liable to any Secured Party for any action taken or omitted to be taken under the Loan Documents, except for losses directly and solely caused by Agent’s gross negligence or willful misconduct. Agent does not assume any responsibility for any failure or delay in performance or any breach by any Obligor, Lender or other Secured Party of any obligations under the Loan Documents. Agent does not make any express or implied representation, warranty or guarantee to Secured Parties with respect to any Obligations, Collateral, Liens, Loan Documents or Obligor. No Agent Indemnitee shall be responsible to Secured Parties for any recitals, statements, information, representations or warranties contained in any Loan Documents or Borrower Materials; the execution, validity, genuineness, effectiveness or enforceability of any Loan Documents; the genuineness, enforceability, collectability, value, sufficiency, location or existence of any Collateral, or the validity, extent, perfection or priority of any Lien therein; the validity, enforceability or collectability of any Obligations; or the assets, liabilities, financial condition, results of operations, business, creditworthiness or legal status of any Obligor or Account Debtor. No Agent Indemnitee shall have any obligation to any Secured Party to ascertain or inquire into the existence of any Default or Event of Default, the observance by any Obligor of any terms of the Loan Documents, or the satisfaction of any conditions precedent contained in any Loan Documents.
Other Responsibilities The Responsibility factors also take account of any responsibility the jobholder may have through the provision of advice and guidance on policies and procedures, research or the adaptation or development of existing or new policies and procedures. An assessment tool has been developed to help ensure that advisory, policy and similar ‘hands off’ responsibilities, such as research or democratic services, are correctly measured and allocated to the appropriate Responsibility factor. It is recommended that jobs are first evaluated on their ‘hands on’ responsibilities under each Responsibility factor and that an assessment is then made of the level of advisory/policy responsibilities and the factor to which it should be allocated.
School Responsibilities Pursuant to §1002.33(8)(e), F.S., the School shall be dissolved under the provisions of law under which the School was organized. Student records and copies of all administrative, operational, and financial records of the School shall be provided to the Sponsor on the date the termination/non-renewal takes effect.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access.
(b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder).
(c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion.
(d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian.
(e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.
Certification Regarding Debarment, Suspension, and Other Responsibility Matters The Contractor identified in Section 1.3 of the General Provisions agrees to comply with the provisions of Executive Office of the President, Executive Order 12549 and 45 CFR Part 76 regarding Debarment, Suspension, and Other Responsibility Matters, and further agrees to have the Contractor’s representative, as identified in Sections 1.11 and 1.12 of the General Provisions execute the following Certification: INSTRUCTIONS FOR CERTIFICATION
1. By signing and submitting this Agreement, the prospective primary participant is providing the certification set out below.
2. The inability of a person to provide the certification required below will not necessarily result in denial of participation in this covered transaction. If necessary, the prospective participant shall submit an explanation of why it cannot provide the certification. The certification or explanation will be considered in connection with the NH Department of Health and Human Services’ (DHHS) determination whether to enter into this transaction. However, failure of the prospective primary participant to furnish a certification or an explanation shall disqualify such person from participation in this transaction.
3. The certification in this clause is a material representation of fact upon which reliance was placed when DHHS determined to enter into this transaction. If it is later determined that the prospective primary participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, DHHS may terminate this transaction for cause or default.
4. The prospective primary participant shall provide immediate written notice to the DHHS agency to whom this Agreement is submitted if at any time the prospective primary participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.
5. The terms “covered transaction,” “debarred,” “suspended,” “ineligible,” “lower tier covered transaction,” “participant,” “person,” “primary covered transaction,” “principal,” “proposal,” and “voluntarily excluded,” as used in this clause, have the meanings set out in the Definitions and Coverage sections of the rules implementing Executive Order 12549: 45 CFR Part 76. See xxxxx://xxx.xxxxxxx.xxx/app/details/CFR-2004-title45-vol1/CFR-2004-title45-vol1-part76/context.
6. The prospective primary participant agrees by submitting this Agreement that, should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by DHHS.
7. The prospective primary participant further agrees by submitting this proposal that it will include the clause titled “Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions,” provided by DHHS, without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions.
8. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that it is not debarred, suspended, ineligible, or involuntarily excluded from the covered transaction, unless it knows that the certification is erroneous. A participant may decide the method and frequency by which it determines the eligibility of its principals. Each participant may, but is not required to, check the Nonprocurement List (of excluded parties) xxxxx://xxx.xxxx.xxx/current/title-22/chapter-V/part-513.
9. Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good faith the certification required by this clause. The knowledge and information of a participant is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.
10. Except for transactions authorized under paragraph 6 of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to other remedies available to the Federal government, DHHS may terminate this transaction for cause or default. PRIMARY COVERED TRANSACTIONS
11. The prospective primary participant certifies to the best of its knowledge and belief, that it and its principals:
11.1. Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency;
11.2. Have not within a three-year period preceding this proposal (Agreement) been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or a contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property;
11.3. Are not presently indicted for otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (l)(b) of this certification; and
11.4. Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default.
12. Where the prospective primary participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal (contract). LOWER TIER COVERED TRANSACTIONS
13. By signing and submitting this lower tier proposal (Agreement), the prospective lower tier participant, as defined in 45 CFR Part 76, certifies to the best of its knowledge and belief that it and its principals:
13.1. Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency.
13.2. Where the prospective lower tier participant is unable to certify to any of the above, such prospective participant shall attach an explanation to this proposal (Agreement).
14. The prospective lower tier participant further agrees by submitting this proposal (Agreement) that it will include this clause entitled “Certification Regarding Debarment, Suspension, Ineligibility, and Voluntary Exclusion - Lower Tier Covered Transactions,” without modification in all lower tier covered transactions and in all solicitations for lower tier covered transactions.
