Progress Payments; Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor’s Applications for Payment on or about the first day of each month during performance of the Work as provided in Paragraph 6.02.A.1 below, provided that such Applications for Payment have been submitted in a timely manner and otherwise meet the requirements of the Contract. All such payments will be measured by the Schedule of Values established as provided in the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no Schedule of Values, as provided elsewhere in the Contract.
1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below but, in each case, less the aggregate of payments previously made and less such amounts as Owner may withhold, including but not limited to liquidated damages, in accordance with the Contract
a. 95 percent of Work completed (with the balance being retainage). If the Work has been 50 percent completed as determined by Engineer, and if the character and progress of the Work have been satisfactory to Owner and Engineer, then as long as the character and progress of the Work remain satisfactory to Owner and Engineer, there will be no additional retainage; and
Progress Payments 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents.
PROGRESS PAYMENT
9.2.1 City shall retain five percent (5%) of the undisputed amount due on each progress payment, or the percentage stated in the Notice Inviting Bids, whichever is greater, as retention to ensure full and complete performance of the Work. Subject to City’s right of withholding under Paragraph 9.4.2 of these General Conditions, City agrees to pay to Contractor within thirty (30) Days of receipt of a properly submitted Application for Payment an amount equal to ninety-five percent (95%), or a lesser amount if corresponding to a higher retention percentage, if applicable, of the sum of the following, excepting therefrom any amounts which are disputed by City:
(i) Construction Manager’s determination of the value, expressed as a percentage of the Contract Sum, of the Work in permanent place that has been tested and accepted as of the end of the preceding month.
(ii) Construction Manager’s determination of the value of materials suitably stored but not yet incorporated into the Work, subject to Paragraph 9.3.6 of these General Conditions.
(iii) Less amounts previously paid.
9.2.2 At any Time after fifty percent (50%) of the Work has been determined by Construction Manager to be completed, City may in its sole discretion, make any of the remaining progress payments in accordance with the calculation in Paragraph 9.2.1 of these General Conditions based on one hundred percent (100%) of City’s determination of the value of the Work in place and of stored materials not yet incorporated into the Work.
9.2.3 Progress payments shall not be construed as City's Acceptance of any or all of the Work and shall not be a waiver of any or all rights City has under the Contract Documents.
XXXXXX’S EXPENDITURES If any action or proceeding is commenced that would materially affect Xxxxxx’s interest in the Collateral or if Borrower fails to comply with any provision of this Agreement or any Related Documents, including but not limited to Borrower’s failure to discharge or pay when due any amounts Borrower is required to discharge or pay under this Agreement or any Related Documents, Lender on Borrower’s behalf may (but shall not be obligated to) take any action that Lender deems appropriate, including but not limited to discharging or paying all taxes, liens, security interests, encumbrances and other claims, at any time levied or placed on any Collateral and paying all costs for insuring, maintaining and preserving any Collateral. All such expenditures incurred or paid by Lender for such purposes will then bear interest at the rate charged under the Note from the date incurred or paid by Lender to the date of repayment by Xxxxxxxx. All such expenses will become a part of the Indebtedness and, at Lender’s option, will (A) be payable on demand; (B) be added to the balance of the Note and be apportioned among and be payable with any installment payments to become due during either (1) the term of any applicable insurance policy; or (2) the remaining term of the Note; or (C) be treated as a balloon payment which will be due and payable at the Note’s maturity.
Payments and Completion Payments may be withheld because of (1) defective work not remedied; (2) failure of contractor to make proper payments to subcontractors, workers, or suppliers; (3) persistent failure to carry out work in acceptance with this Agreement or these general conditions, or (4) legal claims. Final payment will be due after complete release of any and all liens arising out of the contract or submission of receipts or other evidence of payment covering all subcontractors or suppliers who could file such a lien. The contractor agrees to indemnify the Owner against such liens and will refund all monies including costs and reasonable attorney’s fees paid by the owner in discharging the liens. A 10 percent holdback is required by the lender to assure the work has been properly completed and there are no liens against the property.
Costs and Prorations (a) At Closing, the Parties shall prorate, without duplication, as of the Closing Date, the following with respect to the Assets:
(i) Solely to the extent (a) payable by the Company and (b) not covered by Section 1.4(a)(iii) or Section 1.4(a)(iv) below, all ad valorem/personal property taxes and current installments of special assessments levied or assessed with respect to the Assets on a daily basis based upon the fiscal year of the appropriate Taxing Authority on an accrual basis.
(ii) All prepaid items and deposits applicable to the operation of the Assets covering periods prior to and after the Closing Date, including all utilities (including gas, water and electricity). The Company shall pay, or cause to be paid, prior to the Closing, all such amounts for which a xxxx has been received for which payments are due prior to the Closing Date, and Purchaser shall be credited, and Seller shall be debited, with an amount equal to all utility charges for the period from the last day covered by any such xxxx until the Closing Date if such utilities will continue to be received.
(iii) Amounts payable under Leases and Permits and other Assets shall be prorated on an accrual basis. The Company shall pay, or cause to be paid, when due all amounts due thereunder prior to the Closing Date. For such amounts due on or after the Closing Date and reflected on the Closing Statement or the Final Closing Statement, Purchaser shall be credited, and Seller shall be debited, for Seller’s prorated share of such amount. For such amounts due on or after the Closing Date, Seller agrees to pay its prorated share when due or to promptly reimburse Purchaser if paid by Purchaser; provided, however, to the extent funds are available, such amounts shall first be paid from the Escrow Fund. Percentage rents based on advertising revenues for periods including days both before and after the Closing Date, and Seller’s prorated share thereof, shall be estimated in good faith by extrapolating the advertising revenue for the period upon which the percentage rents are based by applying the average monthly revenue for the months (or portions thereof) preceding the Closing, to the months (or portions thereof) following Closing. For the avoidance of doubt, (x) paid-up/pre-paid rental on Sign Locations Leases pre-paid not more than twelve (12) months beyond the Closing Date shall be prorated, but (y) paid-up/pre-paid rental on Sign Locations Leases prepaid more than twelve (12) months beyond the Closing Date and perpetual easements shall not be prorated.
(iv) The Purchase Price shall be decreased by: (a) the pro rata portion of the amount of any remaining balance at the Closing Date of credits for advertisements received prior to the Closing Date or other credits due advertisers from Seller or the Company as of the Closing Date; and (b) pre-billed and/or pre-collected accounts receivable items actually collected and for which outdoor advertising services are to be rendered after the Closing Date.
(v) The Purchase Price shall be increased by any amounts posted as security deposit by CCOI or any of its Affiliates with respect to any Assumed Contract (which deposits are not being refunded to CCOI or its Affiliates but rather being retained by the counterparties for the Company’s account).
(b) Seller has prepared, in good faith, a closing statement (the “Closing Statement”) consistent with the foregoing and otherwise consistent with this Agreement and has delivered it, along with reasonably detailed information showing the manner in which the contents of the Closing Statement were calculated, to Purchaser prior to the date of this Agreement. In preparing the Closing Statement, Seller used the best available information, subject to additional adjustment among the Parties after Closing upon receipt of definitive information or final bills; provided, however, that no such adjustments will be made after the Closing Statement becomes final pursuant to Section 1.4(c).
(c) As soon as practicable after the Closing (but in any event within ninety (90) days after the Closing), Seller shall deliver a final Closing Statement (the “Final Closing Statement”) to Purchaser, which Final Closing Statement shall set forth (among the other information described above) the amount of actual Closing Date Indebtedness. Each Party shall provide to the other Party, reasonable access at reasonable times to the books and records of such Party and to appropriate employees and representatives (including independent accountants) as such other Party shall reasonably request in connection with the preparation and review of the Final Closing Statement, or any component thereof or information contained or referred to therein, as the case may be, including all work papers of the accountants who audited, compiled or reviewed such statements or notices (subject to each Party and its representatives entering into any such access letters required by the other Party’s accountants in connection herewith), and shall otherwise cooperate reasonably and in good faith with such other Party to arrive at a final determination of the amounts set forth in the Final Closing Statement. Unless Purchaser notifies Seller in writing within 15 days after Seller’s delivery of the Final Closing Statement of any objection to the matters set forth in the Final Closing Statement (the “Notice of Objection”), the Final Closing Statement shall become final and binding. Any Notice of Objection shall specify in reasonable detail the basis for the objections set forth therein. If Purchaser provides the Notice of Objection to Seller within such 15-day period, Purchaser and Seller shall, during the 30-day period following Seller’s receipt of the Notice of Objection, attempt in good faith to resolve Purchaser’s objections. If Purchaser and Seller are unable to resolve all such objections within such 30-day period, the matters remaining in dispute that were properly included in the Notice of Objection (the “Unresolved Items”) shall be submitted to a nationally recognized independent public accounting firm mutually acceptable to the Parties (the “Accounting Firm”), which Accounting Firm shall resolve such matters; provided that if Purchaser and Seller are unable to agree upon such firm within ten days after the end of such 30-day period, then the Accounting Firm shall be an accounting or valuation firm of national standing appointed by the American Arbitration Association in New York, New York; provided that such firm shall not be the independent auditor of (or otherwise provide services under a contractual arrangement with) either Purchaser (or any of its Affiliates) or Seller (or any of its Affiliates including iHeartMedia, Inc. or any of its Subsidiaries). Each Party shall furnish the Accounting Firm such work papers and other documents and information pertaining to the Unresolved Items still in dispute as the Accounting Firm may reasonably request and shall be afforded an opportunity to discuss such Unresolved Items with the Accounting Firm at such hearing as the Accounting Firm shall request or permit; provided, that (i) each Party shall provide the other Party with a copy of all materials provided to, and communications with, the Accounting Firm, and (ii) no Party (or any of its Affiliates, advisors or representatives) shall engage in any ex parte communication with the Accounting Firm at any time with respect to the Unresolved Items. The Accounting Firm shall only resolve the Unresolved Items. The resolution of the Unresolved Items by the Accounting Firm shall be final and binding, and the determination of the Accounting Firm shall constitute an arbitral award that is final, binding and non-appealable and upon which a judgment may be entered by a court having jurisdiction over the party against which such determination is to be enforced. Purchaser and Seller shall each pay their own costs and expenses incurred under this Section 1.4; provided, however, that the Accounting Firm shall allocate, and Purchaser and Seller shall pay, its fees, costs and expenses between Purchaser and Seller in accordance with the percentage that the portion of the contested amount not awarded to such Parties bears to the amount actually contested by or on behalf of such Parties.
(d) Within five (5) Business Days after the Final Closing Statement is finalized pursuant to clause (c) of this Section 1.4:
(i) If the Closing Consideration delivered on the Closing Date exceeds the final Purchase Price as adjusted pursuant to this Section 1.4 and contained in the Final Closing Statement; Seller shall pay to Purchaser an amount equal to such excess; and
(ii) If the amount of the final Purchase Price as adjusted pursuant to this Section 1.4 and contained in the Final Closing Statement exceeds Closing Consideration delivered on the Closing Date; Purchaser shall pay Seller an amount equal to such excess. Any amount paid with respect to final adjustments to the Purchase Price made pursuant to this Section 1.4 shall be (i) paid by wire transfer of immediately available funds to an account designated by the receiving Party and (ii) treated as an adjustment of the Purchase Price for applicable tax purposes to the extent permitted by Tax Law.
General Conditions Costs Contractor is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from Owner through Substantial Completion of the Project, plus 30 calendar days. Contractor is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion, plus 30 calendar days, must be approved in advance by Owner. Allowable General Conditions items are identified below and in Exhibit “D” attached to this Agreement. These items shall be included in the General Conditions Cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the Schedule of Values. Items not specifically included below or in Exhibit “D” will not be allowed as General Condition Costs.
Closing Costs and Prorations Taxes and assessments for the current year, if any, shall be prorated between the prior owner of the Personal Property and Buyer as of the date of closing. Seller shall pay one-half (½) of Closing Agent’s closing and escrow fees. Buyer shall pay one-half (½) of Closing Agent’s closing and escrow fees. In addition, Buyer shall pay all other closing costs, including but not limited to: (1) recording fees for the cost of recording the State Deed; (2) the cost for any title insurance purchased at Buyer’s option; (3) lender fees, if any, together with all associated recording fees, if any;
Payments and Computations, Etc (a) All amounts to be paid or deposited by the Seller or the Servicer hereunder or under any other Transaction Document shall be made without reduction for offset or counterclaim and shall be paid or deposited no later than noon (New York, New York time) on the day when due in same day funds to the account for each Purchaser maintained by the applicable Purchaser Agent as may be designated from time to time by such Purchaser Agent to the Seller and the Servicer. All amounts received after 1:00 p.m. (New York, New York time) will be deemed to have been received on the next Business Day. Except as expressly set forth herein, each Purchaser Agent shall distribute the amounts paid to it hereunder for the benefit of the Purchasers in its Purchaser Group to the Purchasers within its Purchaser Group ratably (x) in the case of such amounts paid in respect of Discount and fees, according to the Discount and fees payable to such Purchasers and (y) in the case of such amounts paid in respect of Capital (or in respect of any other obligations other than Discount and fees), according to the outstanding Capital funded by such Purchasers.
(b) The Seller (with respect to amounts payable by the Seller) or the Servicer (with respect to amounts payable by the Servicer), as the case may be, shall, to the extent permitted by law, pay interest on any amount not paid or deposited by the Seller or the Servicer, as the case may be, when due and payable hereunder, at an interest rate equal to 2.00% per annum above the Base Rate, payable on demand; provided, that such rate shall not at any time exceed the maximum rate permitted by applicable Law.
(c) All computations of interest under clause (b) and all computations of Discount, fees and other amounts hereunder shall be made on the basis of a year of 360 days (or 365 or 366 days, as applicable, with respect to Discount or other amounts calculated by reference to the Base Rate) for the actual number of days elapsed. Whenever any payment or deposit to be made hereunder shall be due on a day other than a Business Day, such payment or deposit shall be made on the next Business Day and such extension of time shall be included in the computation of such payment or deposit.
Training Costs All costs and expenses incurred by the Contractor in the training of its employees engaged in Petroleum Operations, and such other training as is required by this Agreement.
