Annual Fee Adjustment Amount Sample Clauses

Annual Fee Adjustment Amount. To provide incentive for Operator ---------------------------- to operate and maintain the Facility in such a way so as to maximize profitability and efficiency of operation, achieve target operating levels of performance, and protect the overall life and viability of the Facility, the O&M Fee earned by Operator shall be subject to an annual adjustment. The amount of such adjustment (the "Annual Fee Adjustment Amount" or "AFAA") shall be the sum of bonuses earned by and/or liquidated damages assessed against Operator in each of six (6) separate categories of evaluation. The six (6) categories of evaluation are: (1) Power Generation, (ii) Change in DMNC, (iii) Steam Delivery, (iv) Net Plant Heat Rate, (v) O&M Costs, and (vi) Subjective Factors. In each category the maximum bonus or liquidated damage will be limited to a specific dollar amount. The AFAA shall be the sum of the bonuses earned and liquidated damages assessed in each individual category and in any Project Year shall never exceed Two Hundred Fifty Thousand and 00/100 Dollars ($250,000.00), plus or minus, as the case may be.
Sample 1
AutoNDA by SimpleDocs

Related to Annual Fee Adjustment Amount

  • Fee Adjustment Fees as provided in this Agreement to be charged to residents of Joplin and the City pursuant to this Agreement may be adjusted based upon the AARC's change in costs subsequent to the previous adjustment. Any individual fee increases will be adjusted only to the extent of an increase in the Consumer Price Index (St. Louis -All Urban Consumers), utilizing the December 12 month period index from the previous year. If a fee increase request is in excess of the Consumer Price Index the city may request to review data on actual costs of each service if needed to document cost increases. In the event an adjustment to documented cost is warranted, AARC shall provide written notice thereof with supporting documentation, by no later than May 1 of each year. All increases shall be subject to annual appropriation by the Joplin City Council. City shall have thirty (30) days to review and request additional supporting documentation. In the event the parties are unable to agree to the cost adjustment, either party shall be entitled to terminate this Agreement as provided herein.

  • Adjustment Amount (a) Schedule 2.16 sets forth a sample calculation of the Adjustment Amount and the Target Adjustment Amount as of the Balance Sheet Date (the “Sample Closing Statement”), including the asset, liability and other line items and accounting principles used in such calculation, and assuming that all of such asset and liability line items that constitute Mallinckrodt Assets or Mallinckrodt Liabilities under this Agreement will be transferred to Mallinckrodt as of the Distribution. (b) Within sixty (60) days after the Distribution Date, Mallinckrodt shall cause to be prepared and delivered to Covidien a statement (the “Closing Statement”) setting forth (i) the Adjustment Amount and the calculation of the Adjustment Amount and (ii) the Target Adjustment Amount and the calculation of the Target Adjustment Amount. The Closing Statement shall be prepared in accordance with the Transaction Accounting Principles, including the use of the same line items and line item entries, set forth on and used in the preparation of the Sample Closing Statement; provided, however, that assets newly acquired and liabilities newly incurred following the date of the Sample Closing Statement which cannot be appropriately placed in line items previously used by Mallinckrodt, but that constitute Mallinckrodt Assets or Mallinckrodt Liabilities, will also be included to the extent consistent with the Transaction Accounting Principles. (c) Within thirty (30) days following receipt by Covidien of the Closing Statement, Covidien shall deliver written notice to Mallinckrodt of any dispute Covidien has with respect to the preparation or content of the Closing Statement (the “Dispute Notice”); provided, however, that if Covidien does not deliver any Dispute Notice to Mallinckrodt within such thirty (30)-day period, the Closing Statement will be final, conclusive and binding on the Parties. Any Dispute Notice shall (i) set forth in reasonable detail the basis for any dispute included therein, the amounts involved and Covidien’s determination of the Adjustment Amount and/or the Target Adjustment Amount (as applicable) and (ii) include only disagreements based on the Adjustment Amount and/or the Target Adjustment Amount (as applicable) not being calculated properly in accordance with this Agreement or containing mathematical errors. Upon receipt by Mallinckrodt of a Dispute Notice, Mallinckrodt and Covidien shall negotiate in good faith to resolve any dispute set forth therein. If Mallinckrodt and Covidien, such good faith effort notwithstanding, fail to resolve any such dispute within fifteen (15) Business Days following receipt by Mallinckrodt of the Dispute Notice (the “Dispute Resolution Period”), then Mallinckrodt and Covidien jointly shall engage, within ten (10) Business Days following the expiration of the Dispute Resolution Period, Ernst & Young LLP or, if Ernst & Young LLP is unavailable or conflicted, another nationally recognized major accounting firm selected jointly by Covidien and Mallinckrodt (the “Independent Accounting Firm”) to resolve any such dispute. If Ernst & Young LLP is unavailable or conflicted and Covidien and Mallinckrodt are unable to agree on the Independent Accounting Firm, then each of Covidien and Mallinckrodt shall select a nationally recognized major accounting firm, and the two (2) firms will mutually select a third nationally recognized major accounting firm to serve as the Independent Accounting Firm. As promptly as practicable, and in any event not more than fifteen (15) days following the engagement of the Independent Accounting Firm, Mallinckrodt and Covidien shall each prepare and submit a presentation detailing each Party’s complete statement of proposed resolution of each issue still in dispute to the Independent Accounting Firm. Mallinckrodt and Covidien shall cause the Independent Accounting Firm to, as soon as practicable after the submission of the presentations described in the immediately preceding sentence and in any event not more than thirty (30) days following such presentations, make a final determination, binding on the Parties, of the appropriate amount of each of the line items that remain in dispute as indicated in the Dispute Notice. With respect to each disputed line item, such determination, if not in accordance with the position of either Covidien or Mallinckrodt, shall not be in excess of the higher, nor less than the lower, of the amounts set forth by Mallinckrodt in the Closing Statement or by Covidien in the Dispute Notice, as applicable. Notwithstanding the foregoing, the scope of the disputes to be resolved by the Independent Accounting Firm shall be limited to whether any determination of the Adjustment Amount and/or the Target Adjustment Amount (as applicable) was properly calculated in accordance with the Transaction Accounting Principles, and the Independent Accounting Firm is not to make any other determination, including any determination as to whether GAAP was followed, to the extent GAAP is inconsistent with the Transaction Accounting Principles. All fees and expenses relating to the work, if any, to be performed by the Independent Accounting Firm shall be borne equally by Covidien and Mallinckrodt. All determinations made by the Independent Accounting Firm, and the Closing Statement, as modified by the Independent Accounting Firm, will be final, conclusive and binding on the Parties, absent fraud or manifest error. (d) For purposes of complying with the terms set forth in this Section 2.16, Mallinckrodt and Covidien shall cooperate with and make available to each other and their respective Representatives all information, records, data and working papers, in each case, to the extent related to the Mallinckrodt Assets, Mallinckrodt Liabilities or Mallinckrodt Business, and shall permit access to its facilities and personnel, as may be reasonably required in connection with the preparation and analysis of the Closing Statement and the resolution of any disputes thereunder. (e) If the Adjustment Amount, as finally determined pursuant to Section 2.16(c), is greater than the Target Adjustment Amount, as finally determined pursuant to Section 2.16(c), by at least $20 million, then Mallinckrodt shall pay or cause to be paid an amount in cash equal to the difference from the first dollar (i.e., without regard to the $20 million threshold) to Covidien by wire transfer of immediately available funds to an account or accounts designated in writing by Covidien to Mallinckrodt. If the Adjustment Amount, as finally determined pursuant to Section 2.16(c), is less than the Target Adjustment Amount, as finally determined pursuant to Section 2.16(c), by at least $20 million, then Covidien shall pay or cause to be paid an amount in cash equal to the difference from the first dollar (i.e., without regard to the $20 million threshold) to Mallinckrodt by wire transfer of immediately available funds to an account or accounts designated in writing by Mallinckrodt to Covidien. Any such payment pursuant to this Section 2.16(e) is to be made within five (5) Business Days of the date on which the Adjustment Amount and the Target Adjustment Amount have been finally determined pursuant to this Section 2.16.

  • Fee Adjustments The fixed fees and other fees expressed as stated dollar amounts in this Schedule C and in this Agreement are subject to annual increases, commencing on the one-year anniversary date of the date of this Agreement, in an amount equal to the percentage increase in consumer prices for services as measured by the United States Consumer Price Index entitled “All Services Less Rent of Shelter,” or a similar index should such index no longer be published, since such one-year anniversary or since the date of the last fee increase, as applicable.

  • Annual Adjustment At the end of each Fiscal Year and following receipt by Manager of the annual accounting referred to in Article 10, an adjustment will be made to such annual account, if necessary and if available, so that the appropriate amount shall have been deposited in the Reserve.

  • Gross Settlement Amount Except as otherwise provided by Paragraph 9 below, Defendant promises to pay $633,000.00 and no more as the Gross Settlement Amount and to separately pay any and all employer payroll taxes owed on the Wage Portions of the Individual Class Payments. Defendant has no obligation to pay the Gross Settlement Amount (or any payroll taxes) prior to the deadline stated in Section 5 of this Agreement. The Administrator will disburse the entire Gross Settlement Amount without asking or requiring Participating Class Members or Aggrieved Employees to submit any claim as a condition of payment. None of the Gross Settlement Amount will revert to Defendant.

  • Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.

  • Performance Adjustment Rate Except as otherwise provided in sub-paragraph (e) of this paragraph 3, the Performance Adjustment Rate is 0.02% for each percentage point (the performance of the Portfolio and the Index each being calculated to the nearest .01%) that the Portfolio's investment performance for the performance period was better or worse than the record of the Index as then constituted. The maximum performance adjustment rate is 0.20%. For purposes of calculating the performance adjustment of the portfolio, the portfolio's investment performance will be based on the performance of the retail class. The performance period will commence with the first day of the first full month following the retail class's commencement of operations. During the first eleven months of the performance period for the retail class, there will be no performance adjustment. Starting with the twelfth month of the performance period, the performance adjustment will take effect. Following the twelfth month a new month will be added to the performance period until the performance period equals 36 months. Thereafter the performance period will consist of the current month plus the previous 35 months. The Portfolio's investment performance will be measured by comparing (i) the opening net asset value of one share of the retail class of the Portfolio on the first business day of the performance period with (ii) the closing net asset value of one share of the retail class of the Portfolio as of the last business day of such period. In computing the investment performance of the retail class of the Portfolio and the investment record of the Index, distributions of realized capital gains, the value of capital gains taxes per share paid or payable on undistributed realized long-term capital gains accumulated to the end of such period and dividends paid out of investment income on the part of the Portfolio, and all cash distributions of the securities included in the Index, will be treated as reinvested in accordance with Rule 205-1 or any other applicable rules under the Investment Advisers Act of 1940, as the same from time to time may be amended.

  • Purchase Price Adjustment (a) Within 90 days following the Closing, the Buyer shall prepare and deliver, or cause to be prepared and delivered, to the Seller a statement (the “Closing Schedule”) setting forth: (i) the Buyer’s determination of the actual amounts of (A) the Adjustment Amount, including the Final Adjustment Amount Overage or the Final Adjustment Amount Underage (the “Final Adjustment Amount”), and (B) the Seller Indebtedness Amount, in each case as of 12:01 a.m. Eastern Time on the Closing Date without taking into account any of the transactions to be completed on the Closing Date in accordance with the terms of this Agreement; (ii) a calculation of any adjustments to the Closing Payment based on such calculations (the adjusted Closing Payment as a result of such calculation being the “Final Closing Payment”); and (iii) a calculation of the accounts receivable contained in the Preliminary Adjustment Amount that were not collected by Buyer within the thirty (30) days immediately following the Closing and the accounts receivable existing at the Closing but not taken into account in calculating the Adjustment Amount (the “Excluded AR”). (b) Within fifteen (15) days after delivery of the Closing Schedule, the Seller may deliver a notice to Buyer either: (i) concurring with the Closing Schedule (a “Notice of Concurrence”); or (ii) disagreeing therewith (a “Notice of Disagreement”). If the Seller delivers a Notice of Disagreement, then it shall be accompanied by the Seller’s proposed revisions to the Closing Schedule. If the Seller fails to deliver any notice within such 15-day period, the Seller shall be deemed to have delivered a Notice of Concurrence. (c) If a Notice of Concurrence is delivered or deemed delivered, and if the Final Closing Payment is less than the Closing Payment, the Buyer shall be entitled to payment out of the Royalty Consideration in the full amount of such shortfall. If a Notice of Concurrence is delivered or deemed delivered, and the Final Closing Payment is greater than the Closing Payment, Buyer shall pay to the Seller the full amount of such excess (with such payment being in shares of Buyer Common Stock priced at $1.50 per share) within thirty (30) days of the delivery of the Notice of Concurrence. (d) If a Notice of Disagreement is delivered, then the Seller and the Buyer shall, during the 15-day period following such delivery (the “Negotiation Period”), use commercially reasonable efforts to agree on the Final Adjustment Amount. If, during such period, the Seller and the Buyer are unable to reach agreement, they promptly shall engage a nationally recognized certified public accounting firm reasonably acceptable to each such party (the “Independent Auditor”) to resolve the disagreement, and any such resolution shall be final, conclusive and binding upon the parties hereto, absent fraud or manifest error. To the extent the Final Closing Payment as determined by the Independent Auditor is less than the Closing Payment, the Buyer shall be entitled to payment out of the Royalty Consideration in the full amount of such shortfall. To the extent the Final Closing Payment as determined by the Independent Auditor is more than the Closing Payment, the Buyer shall pay to the Seller the full amount of such excess (with such payment being in shares of Buyer Common Stock priced at $1.50 per share) within thirty (30) days of such resolution. (e) Each of the Seller and the Buyer shall pay fifty percent (50%) of the fees and expenses of the Independent Auditor.

  • Settlement Amount If the Non-Defaulting Party has declared an Early Termination Date pursuant to Section 7.2(b), the Non-Defaulting Party shall have the right to (i) accelerate all amounts owing between the Defaulting Party and the Non-Defaulting Party and to liquidate and terminate the undertakings set forth in this Agreement as between the Defaulting Party and the Non-Defaulting Party; and (ii) withhold any payments due to the Defaulting Party under this Agreement pending payment of the Termination Payment. The Non-Defaulting Party will calculate, in a commercially reasonable manner, the Settlement Amount with respect to the Defaulting Party’s obligations under the Agreement and shall net the Settlement Amount in the manner provided for in Section 7.3(c).

  • Performance Adjustment One-twelfth of the annual Performance Adjustment Rate will be applied to the average of the net assets of the Portfolio (computed in the manner set forth in the Fund's Declaration of Trust or other organizational document) determined as of the close of business on each business day throughout the month and the performance period.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!