Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.
(b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
Log Reviews All systems processing and/or storing PHI COUNTY discloses to 11 CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY 12 must have a routine procedure in place to review system logs for unauthorized access.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Product Quality (a) Tesoro warrants that all Products delivered under this Agreement or any Purchaser Order shall meet the latest applicable pipeline specifications or otherwise mutually agreed upon specifications for that Product upon receipt at the applicable Terminal and contain no deleterious substances or concentrations of any contaminants that may make it or its components commercially unacceptable in general industry application. Tesoro shall not deliver to any of the Terminals any Products which: (i) would in any way be injurious to any of the Terminals; (ii) would render any of the Terminals unfit for the proper storage of similar Products; (iii) would contaminate or otherwise downgrade the quality of the Products stored in commingled storage; (iv) may not be lawfully stored at the Terminals; or (v) otherwise do not meet applicable Product specifications for such Product that are customary in the location of the Terminal. If, however, there are Products that do not have such applicable specifications, the specifications shall be mutually agreed upon by the Parties. Should Tesoro’s commingled Products not meet or exceed the minimum quality standards set forth in this Agreement or any applicable Terminal Service Order, Tesoro shall be liable for all loss, damage and cost incurred thereby, including damage to Products of third parties commingled with Tesoro’s unfit Products.
(b) TLO shall have the right to store compatible Products received for Tesoro’s account with Products belonging to TLO or third parties in TLO’s commingled storage tanks. TLO shall handle Tesoro’s fungible Products in accordance with TLO’s prevailing practices and procedures for handling such Products. The quality of all Products tendered into commingled storage for Tesoro’s account shall be verified either by Tesoro’s refinery analysis or supplier’s certification, such that Products so tendered shall meet TLO’s Product specifications. All costs for such analysis shall be borne solely by Tesoro. TLO shall have the right to sample any Product tendered to the Terminals hereunder. The cost of such sampling shall be borne solely by TLO. All Products returned to Tesoro shall meet or exceed Product specifications in effect on the date the Products are delivered to Tesoro. Notwithstanding any other provision herein, any and all Products that leave the Terminals shall meet all relevant ASTM, EPA, federal and state specifications, and shall not leave the Terminals in the form of a sub-octane grade Product.
(c) TLO shall exercise reasonable care to ensure that all Products delivered by third parties into commingled storage with Tesoro’s Products meet applicable Product specifications for such Product that are customary in the location of the Terminal. In the event that Tesoro’s Products are commingled with third-party Products that do not meet or exceed the minimum quality standards set forth in this Agreement or any Terminal Service Order, TLO shall be liable for all loss, damage and cost incurred thereby.
Program Review The State ECEAP Office will conduct a review of each contractor’s compliance with the ECEAP Contract and ECEAP Performance Standards every four years. The review will involve ECEAP staff and parents. After the Program Review, the State ECEAP Office will provide the contractor with a Program Review report. The contractor must submit an ECEAP Corrective Action Plan for non-compliance with ECEAP Performance Standards. The Plan must be approved by the State ECEAP Office.
Project Review A. Programmatic Allowances
1. If FEMA determines that the entire scope of an Undertaking conforms to one or more allowances in Appendix B of this Agreement, with determinations for Tier II Allowances being made by SOI-qualified staff, FEMA shall complete the Section 106 review process by documenting this determination in the project file, without SHPO review or notification.
2. If the Undertaking involves a National Historic Landmark (NHL), FEMA shall notify the SHPO, participating Tribe(s), and the NPS NHL Program Manager of the NPS Midwest Regional Office that the Undertaking conforms to one or more allowances. FEMA shall provide information about the proposed scope of work for the Undertaking and the allowance(s) enabling FEMA’s determination.
3. If FEMA determines any portion of an Undertaking’s scope of work does not conform to one or more allowances listed in Appendix B, FEMA shall conduct expedited or standard Section 106 review, as appropriate, for the entire Undertaking in accordance with Stipulation II.B, Expedited Review for Emergency Undertakings, or Stipulation II.C, Standard Project Review.
4. Allowances may be revised and new allowances may be added to this Agreement in accordance with Stipulation IV.A.3, Amendments.
B. Expedited Review for Emergency Undertakings
Product Testing No later than [**] prior to a scheduled Delivery ARIAD US shall send to ARIAD SWISSCO the Delivery Documents for review. Following such review, unless within [**] of receipt of the Delivery Documents ARIAD SWISSCO gives written notice of rejection of the Product to be delivered, stating the reasons for such rejection, the Delivery shall proceed, and both Parties shall organize the same. Upon arrival at ARIAD SWISSCO nominated site it shall visually inspect the shipment of the Product to identify any damage to the external packaging. ARIAD SWISSCO may reject any shipment (or portion thereof) of the Product that is damaged by providing to ARIAD US reasonable evidence of damage within [**] after Delivery of such Product. If ARIAD SWISSCO does not so reject any shipment (or portion thereof) of the Product within [**] of Delivery of such Product, ARIAD SWISSCO shall be deemed to have accepted such shipment of the Product; provided, however, that in the case of the Product having any Latent Defect, ARIAD SWISSCO shall notify ARIAD US promptly once it becomes aware that a Product contains a Latent Defect and subsequently may reject such Product by giving written notice to ARIAD US of ARIAD SWISSCO’s rejection of such Product and shipping a representative sample of such Product or other evidence of Non-Conformance to ARIAD US within [**] after becoming aware of such Latent Defect, which notice shall include a description of the Latent Defect.
Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
