Appeal Procedure for Suspension Without Pay or Demotion or Dismissal Sample Clauses

Appeal Procedure for Suspension Without Pay or Demotion or Dismissal. 1865 Hearing Authority 1866 23.5.5.1 The hearing will be conducted before an arbitrator selected from 1867 the list provided, in rotational order.
AutoNDA by SimpleDocs
Appeal Procedure for Suspension Without Pay or Demotion or Dismissal 

Related to Appeal Procedure for Suspension Without Pay or Demotion or Dismissal

  • Dismissal or Suspension Grievances (a) In the case of a dispute arising from an employee’s dismissal, the grievance may be filed directly at Step 3, within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal. (b) In the case of a dispute arising from an employee’s suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within (30) days of the employee receiving notice of suspension.

  • Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal. (b) In the case of a dispute arising from an employee's suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within thirty (30) days of the employee receiving notice of suspension.

  • Service Termination, Cancellation, or Suspension If you wish to cancel the Service, you may contact us as set forth in Section 6 of the General Terms above. Any payment(s) that have begun processing before the requested cancellation date will be processed by us. You agree that we may terminate or suspend your use of the Service at any time and for any reason or no reason. Neither termination, cancellation nor suspension shall affect your liability or obligations under this Agreement.

  • TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:

  • Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.

  • TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.

  • Definition of a Grievance A grievance is defined as a dispute or disagreement as to the interpretation or application of the specific terms and conditions of this AGREEMENT.

  • Suspension or Termination of Sales Consistent with standard market settlement practices, the Company or the Agent may, upon notice to the other party hereto in writing or by telephone (confirmed immediately by verifiable email), suspend any sale of Shares, and the period set forth in an Issuance Notice shall immediately terminate; provided, however, that (A) such suspension and termination shall not affect or impair either party’s obligations with respect to any Shares placed or sold hereunder prior to the receipt of such notice; (B) if the Company suspends or terminates any sale of Shares after the Agent confirms such sale to the Company, the Company shall still be obligated to comply with Section 3(b)(v) with respect to such Shares; and (C) if the Company defaults in its obligation to deliver Shares on a Settlement Date, the Company agrees that it will hold the Agent harmless against any loss, claim, damage or expense (including, without limitation, penalties, interest and reasonable legal fees and expenses), as incurred, arising out of or in connection with such default by the Company. The parties hereto acknowledge and agree that, in performing its obligations under this Agreement, the Agent may borrow Common Shares from stock lenders in the event that the Company has not delivered Shares to settle sales as required by subsection (v) above, and may use the Shares to settle or close out such borrowings. The Company agrees that no such notice shall be effective against the Agent unless it is made to the persons identified in writing by the Agent pursuant to Section 3(b)(i).

  • Termination or Suspension Under Federal Law (i) If the Employee is removed and/or permanently prohibited from participating in the conduct of the Company’s affairs by an order issued under Sections 8(e)(iv) or 8(g)(i) of the Federal Deposit Insurance Act (“FDIA”) (12 U.S.C. 1818(e)(4) and (g)(1)), all obligations of the Company under this Agreement shall terminate, as of the effective date of the order, but vested rights of the Employee shall not be affected. (ii) If the Bank is in default (as defined in Section 3(x)(1) of the FDIA), all obligations under this Agreement shall terminate as of the date of default; but the vested rights of the Employee shall not be affected. (iii) All obligations under this Agreement shall terminate, except to the extent it is determined that the continuation of this Agreement is necessary for the continued operation of the Bank; (A) by the OCC or its designee, at the time that the Federal Deposit Insurance Corporation (“FDIC”) enters into an agreement to provide assistance to or on behalf of the Bank under the authority contained in Section 13(c) of FDIA; or (B) by the OCC, or its designee, at the time that the OCC or its designee approves a supervisory merger to resolve problems related to operation of the Bank or when the Bank is determined by the OCC to be in an unsafe or unsound condition. Such action shall not affect any vested rights of the Employee. (iv) If a notice served under Section 8(e)(3) or (g)(1) of the FDIA suspends and/or temporarily prohibits the Employee from participating in the conduct of the Bank’s affairs, the Bank’s obligations under this Agreement shall be suspended as of the date of such service, unless stayed by appropriate proceedings. However, the vested rights of the Employee as of the date of suspension will not be affected. If the charges in the notice are dismissed, the Bank may in its discretion (A) pay the Employee all or part of the compensation withheld while its contract obligations were suspended, and (B) reinstate (in whole or in part) any of its obligations which were suspended.

  • Dismissal and Suspension Grievance All dismissals and suspensions will be subject to formal grievance procedure under Article 7 of this Agreement. A copy of the written notice of dismissal or suspension shall be forwarded to the President of the Union within five (5) days of the action being taken.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!