Appointment of Key Sub-Contractors The Supplier shall ensure that all Sub-Contracts contain a provision: requiring the Supplier to pay any undisputed sums which are due from it to the Sub-Contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice; requiring that any invoices submitted by a Sub-Contractor shall be considered and verified by the Supplier in a timely fashion and that undue delay in doing so shall not be sufficient justification for failing to regard an invoice as valid and undisputed; requiring the Sub-Contractor to include in any Sub-Contract which it in turn awards suitable provisions to impose, as between the parties to that Sub-Contract, requirements to the same effect as those required by sub-clauses 5.17.1 and 5.17.2 directly above; and conferring a right to the Customer to publish the Supplier’s compliance with its obligation to pay undisputed invoices within the specified payment period. The Supplier shall pay any undisputed sums which are due from it to a Sub-Contractor within thirty (30) days from the receipt of a valid invoice. Any invoices submitted by a Sub-Contractor to the Supplier shall be considered and verified by the Supplier in a timely fashion. Undue delay in doing so shall not be sufficient justification for the Supplier failing to regard an invoice as valid and undisputed. Notwithstanding any provision of Clauses 9.2 (Confidentiality) and 13 (Publicity, Media and Official Enquiries) if the Supplier notifies the Customer that the Supplier has failed to pay an undisputed Sub-Contractor’s invoice within thirty (30) days of receipt, or the Customer otherwise discovers the same, the Customer shall be entitled to publish the details of the late or non-payment (including on Government websites and in the press).
Texas Education Code Chapter 22 Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide service s to obtain criminal history record information regarding covered employees. Contractors must certify to the district t hat they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a sch ool district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing dutie s related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the o ffense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined abo ve. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure tha t the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain t hese precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history. (2) If Contractor receives information that a covered employee subsequently has a reported criminal history, Contra ctor will immediately remove the covered employee from contract duties and notify the District in writing within 3 busi ness days. (3) Upon request, Contractor will provide the District with the name and any other requested information of covered employees so that the District may obtain criminal history record information on the covered employees. (4) If the District objects to the assignment of a covered employee on the basis of the covered employee's criminal h istory record information, Contractor agrees to discontinue using that covered employee to provide services at the District. Noncompliance or misrepresentation regarding this certification may be grounds for contract termination. None Texas Business and Commerce Code § 272 Requirements as of 9-1-2017 SB 807 prohibits construction contracts to have provisions requiring the contract to be subject to the laws of anothe r state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract wit h such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The t erm also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLI CABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WH EN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 7 5 Texas Government Code 2270 Verification Form Texas Government Code 2270 Verification Form Texas 2017 House Xxxx 89 has been signed into law by the governor and as of September 1, 2017 will be codified as Texas Government Code § 2270 and 808 et seq. The relevant section addressed by this form reads as follows: Texas Government Code Sec. 2270.002. PROVISION REQUIRED IN CONTRACT. A governmental entity may not ent er into a contract with a company for goods or services unless the contract contains a written verification from the c ompany that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract.engaged by ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx,XX,00000 verify by this writing that the above-named company affirms that it (1) does not boycott Israel; and (2) will not boycot t Israel during the term of this contract, or any contract with the above-named Texas governmental entity in the futur e. I further affirm that if our company’s position on this issue is reversed and this affirmation is no longer valid, that t he above-named Texas governmental entity will be notified in writing within one (1) business day and we understand that our company’s failure to affirm and comply with the requirements of Texas Government Code 2270 et seq. shall be grounds for immediate contract termination without penalty to the above-named Texas governmental entity. AND our company is not listed on and we do not do business with companies that are on the the Texas Comptroller of Pu blic Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://x xxxxxxxxxx.xxxxx.xxx/xxxxxxxxxx/xxxx/xxxxxxx-xxxxxxxxx.xxx I swear and affirm that the above is true and correct. YES
Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history. (2) If Contractor receives information that a covered employee subsequently has a reported criminal history, Contractor will immediately remove the covered employee from contract duties and notify the District in writing within 3 business days. (3) Upon request, Contractor will provide the District with the name and any other requested information of covered employees so that the District may obtain criminal history record information on the covered employees. (4) If the District objects to the assignment of a covered employee on the basis of the covered employee's criminal history record information, Contractor agrees to discontinue using that covered employee to provide services at the District. Noncompliance or misrepresentation regarding this certification may be grounds for contract termination. None Texas Business and Commerce Code § 272 Requirements as of 9-1-2017 SB 807 prohibits construction contracts to have provisions requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 7 5 Texas Government Code 2270 Verification Form Texas Government Code 2270 Verification Form Texas 2017 House Xxxx 89 has been signed into law by the governor and as of September 1, 2017 will be codified as Texas Government Code § 2270 and 808 et seq. The relevant section addressed by this form reads as follows: Texas Government Code Sec. 2270.002. PROVISION REQUIRED IN CONTRACT. A governmental entity may not enter into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract engaged by: ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx,XX,00000 I verify by this writing that the above-named company affirms that it (1) does not boycott Israel; and (2) will not boycott Israel during the term of this contract, or any contract with the above-named Texas governmental entity in the future. I further affirm that if our company’s position on this issue is reversed and this affirmation is no longer valid, that the above-named Texas governmental entity will be notified in writing within one (1) business day and we understand that our company’s failure to affirm and comply with the requirements of Texas Government Code 2270 et seq. shall be grounds for immediate contract termination without penalty to the above-named Texas governmental entity. AND Our company is not listed on and we do not do business with companies that are on the the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf I swear and affirm that the above is true and correct. YES
Contractor’s Federal Employment Verification Certification The Contractor is registered with, authorized to use, is using and will continue to use, the federal work authorization program throughout the term of the contract, and holds the following authorization: User Identification Number: Date of Authorization: Date WITNESSETH, that the Contractor and the Owner, for the consideration set forth herein, the adequacy and sufficiency of which is hereby acknowledged by each party, agree as follows:
Appointment Procedures 20.06.01 When a vacancy occurs, the University Librarian will send written notification to all Librarians stating the plans for replacement and the disposition of duties within one month after such Librarian position becomes vacant. The University Librarian shall provide a monthly update to Librarian members on the progress of his/her plans for replacement and disposition of duties.
Appointment of Stewards A. The Union will certify to the Employer in writing a xxxxxxx or stewards and alternates in accordance with the fol- lowing general guidelines. Where more than one xxxxxxx is appointed, one shall be designated chief xxxxxxx. The selection and appointment of stewards or chief stewards is the sole and exclusive function of the Union. Stewards will be certified to represent employees in specific work location(s) on their tour; provided no more than one xxxxxxx may be certified to repre- sent employees in a particular work location(s). The number of stewards certified shall not exceed, but may be less than, the number provided by the formula hereinafter set forth. Employees in the same craft per tour or station Up to 49 1 xxxxxxx 50 to 99 2 stewards 100 to 199 3 stewards 200 to 499 5 stewards 500 or more 5 stewards plus additional xxxxxxx for each 100 employees
Leave of Absence for Employees Who Serve as Local Coordinators for the Ontario Nurses' Association An employee who serves as Local Coordinator for the Ontario Nurses' Association shall be granted leave of absence without pay up to a total of thirty-five (35) days annually. Leave of absence for Local Coordinators for the Ontario Nurses' Association will be separate from the Union leave provided in (a) above.
Certification for Federal-Aid Contracts Lobbying Activities A. The CONSULTANT certifies, by signing and submitting this Contract, to the best of its knowledge and belief after diligent inquiry, and other than as disclosed in writing to the LPA prior to or contemporaneously with the execution and delivery of this Contract by the CONSULTANT, the CONSULTANT has complied with Section 1352, Title 31, U.S. Code, and specifically, that:
Appointment Procedure (1) The Advisory Committee shall establish a list of the most suitable candidates to be appointed as judges of the Court, in accordance with the Statute.
Replacement of Key Personnel The Engineer must notify the State in writing as soon as possible, but no later than three business days after a project manager or other key personnel is removed from association with this contract, giving the reason for removal.
