Assistance with Permits and Utility Agreements Sample Clauses

Assistance with Permits and Utility Agreements. Without derogating from the Contractor’s responsibilities under Section 5.6 to obtain all permits and municipal approvals required for the Project and all required arrangements relating to utilities, railways and drainage (including but not limited to the “Utility Agreements” contemplated by Section 4.8), the Province shall, in response to any reasonable request by the Contractor in relation to such required arrangements, provide the Contractor with such reasonable assistance as the Province is able to offer without unduly fettering its executive discretion or pursuing amendment of any legislation or subordinate legislation, but otherwise including, in any case where the Province concludes that a third party is acting unreasonably in relation to the shared-use nature of the TUC, the exercise by the Province of all legal rights and remedies available to it in relation to such third party, to the extent it is reasonable in the circumstances for the Province to exercise such legal rights and remedies. In the event that the Contractor, despite acting reasonably and prudently and making all commercially reasonable efforts, and despite taking all reasonable mitigation measures (including, to the extent practicable, considering modifications to the Contractor’s Designs): (a) experiences a delay in the Project (measured on a critical path basis having regard to the Contractor’s Construction Schedule) of at least 30 days as a result of being unable to arrange or enforce performance of any particular Utility Agreement (as defined in Section 4.8) other than drainage agreements, then any delay after the initial 30 day delay period shall be treated as if it were a Relief Event, except that: (i) the Province shall not share in any costs occasioned by the initial 30 day delay period; and (ii) after the initial 30 day period, the Province shall contribute one-half of the incremental costs occasioned to the Contractor by the further delay, and the Contractor shall absorb the other one-half; or (b) incurs direct out-of-pocket costs billed by utilities to the Contractor pursuant to Utility Agreements for relocation, power hook-ups or other expenses (collectively, “Utility Costs”) in relation to the Project (whether incurred during the Construction Period or during the Operating Period) in aggregate exceeding $35,000,000, the Province shall, upon receipt of appropriate invoices and supporting documentation reimburse the Contractor for: (i) one-half of the amount by which the ...
Sample 1See All (5)
AutoNDA by SimpleDocs
Assistance with Permits and Utility Agreements. The Design-Builder shall provide the City with prompt notice of each application that the Design-Builder makes to a regulator for a permit or approval in respect of the Project. Without derogating from the Design-Builder’s responsibilities under this Agreement and the CCDC to obtain all permits and approvals required for the Project, and to make all required arrangements relating to utilities, the City shall, in response to any reasonable request by the Design-Builder in relation to such permits and approvals and required arrangements, provide the Design-Builder with such reasonable assistance as the City is able to offer or arrange without unduly fettering its executive discretion or pursuing amendment of any legislation or subordinate legislation, but otherwise including taking any action required to obtain a permit or approval which only the City can take and which cannot be taken by the Design-Builder on the City’s behalf, and in any case where the City concludes that a third party is acting unreasonably in relation to the negotiation or issuance of such permits, approvals or required arrangements, the exercise by the City of all legal rights and remedies available to it in relation to such third party, to the extent it is reasonable in the circumstances for the City to exercise such legal rights and remedies. The Design-Builder shall provide notice to the City of unreasonable delay experienced by the Design-Builder in obtaining permits and approvals required for the Project or in making required arrangements with utilities as soon as practicable after becoming aware of the delay, including details of the cause or perceived cause of the delay and the efforts to date and anticipated further efforts of the Design-Builder to prevent or minimize the duration of the delay.
Sample 1

Related to Assistance with Permits and Utility Agreements

  • Compliance with Laws, Contracts, Licenses, and Permits The Borrower and the Guarantors will, and will cause each of their respective Subsidiaries to, and, to the extent permitted by the terms of the Leases, will cause the Operators of the Pool Properties to, comply in all respects with (i) all Applicable Laws and regulations now or hereafter in effect wherever its business is conducted, including all Environmental Laws, (ii) the provisions of its corporate charter, partnership agreement, limited liability company agreement or declaration of trust, as the case may be, and other charter documents and bylaws, (iii) all agreements and instruments to which it is a party or by which it or any of its properties may be bound, (iv) all applicable decrees, orders, and judgments, and (v) all licenses and permits required Applicable Laws for the conduct of its business or the ownership, use or operation of its properties, except where failure so to comply with either clause (i) or (v) would not result in the material non-compliance with the items described in such clauses. If any authorization, consent, approval, permit or license from any officer, agency or instrumentality of any government shall become necessary or required in order that the Borrower, any Guarantor or their respective Subsidiaries may fulfill any of its obligations hereunder, the Borrower, such Guarantor or such Subsidiary will promptly take or cause to be taken all steps necessary to obtain such authorization, consent, approval, permit or license and furnish the Agent and the Lenders with evidence thereof. The Borrower shall develop and implement such programs, policies and procedures as are necessary to comply with the Patriot Act and shall promptly advise Agent in writing in the event that the Borrower shall determine that any investors in the Borrower are in violation of such act.

  • Compliance with Laws; Licenses and Permits (a) The Transferred Subsidiaries, the Business, the Business Real Property and, with respect to the Business, Sellers and Controlled Affiliates are, and to the Knowledge of Sellers, the Joint Venture is, and for the past three (3) years have been, in compliance in all material respects with all applicable Laws. (b) Section 2.12(b) of the Seller Disclosure Letter sets forth a true and complete list of all Permits (other than PMAs and DERs) primarily relating to, or used or held for use in the operation or conduct of, or in connection with, the Business as conducted as of the date hereof, including special use or conditional use Permits relating to zoning requirements (collectively, the “Business Permits”) that are material to the Business, and the legal owner of such Business Permits; provided, that all FAA certificates and aviation certificates issued by any foreign equivalent Governmental Authority shall be deemed to be material to the Business for purposes of this Section 2.12(b). The Business Permits set forth in Section 2.12(b) of the Seller Disclosure Schedule represent all material Permits necessary for the lawful conduct of the Business as conducted as of the date hereof. The Business Permits are valid and in full force and effect, neither Sellers, their Controlled Affiliates, nor any of the Transferred Subsidiaries are or have during the past three (3) years been in default under the Business Permits, and no suspension, revocation, cancellation or material modification of any Business Permit is pending or, to the Knowledge of Sellers, has been threatened, except for any default pursuant to any such Business Permit or proceeding to suspend, revoke, cancel or modify any such Business Permit as would not, individually or in the aggregate, be (or reasonably be expected to be) material to the Business, taken as a whole. (c) Since April 1, 2018, none of the Transferred Subsidiaries, the Business or, with respect to the Business, Sellers or any other Controlled Affiliates thereof, any of their respective officers, directors, employees, or, to the Knowledge of Sellers, other representatives or agents, in each case, with respect to the Business, or, to the Knowledge of Sellers, the Joint Venture, has taken any action in violation of the U.S. Foreign Corrupt Practices Act of 1977, the UK Bribery Act 2010, all Laws enacted to implement the OECD Convention on Combating Bribery of Foreign Officials in International Business Transactions and all other applicable Laws relating to bribery, corruption, kick-backs or other improper or unlawful payments (regardless of the form, whether in money, property, services or otherwise) (collectively, “Anti-Corruption and Anti-Bribery Laws”). For purposes of this Section 2.12(c), “Knowledge of the Sellers” means the actual knowledge or awareness of a high probability of the existence of such circumstance, unless the individual actually believes that such circumstance does not exist, as of the Business Day prior to the date hereof, of the individuals set forth on Section 9.1(d) of the Seller Disclosure Letter.

  • Compliance with laws; payment of Permits/Licenses All services to be performed by Contractor pursuant to this Agreement shall be performed in accordance with all applicable Federal, State, County, and municipal laws, including, but not limited to, Health Insurance Portability and Accountability Act of 1996 (HIPAA) and all Federal regulations promulgated thereunder, as amended, and the Americans with Disabilities Act of 1990, as amended, and Section 504 of the Rehabilitation Act of 1973, as amended and attached hereto and incorporated by reference herein as Attachment “I,” which prohibits discrimination on the basis of handicap in programs and activities receiving any Federal or County financial assistance. Such services shall also be performed in accordance with all applicable ordinances and regulations, including, but not limited to, appropriate licensure, certification regulations, provisions pertaining to confidentiality of records, and applicable quality assurance regulations. In the event of a conflict between the terms of this agreement and State, Federal, County, or municipal law or regulations, the requirements of the applicable law will take precedence over the requirements set forth in this Agreement. Contractor will timely and accurately complete, sign, and submit all necessary documentation of compliance.

  • Compliance with Law; Permits (a) The Company and its Subsidiaries are, and since March 1, 2011 have been, in compliance with and are not in default under or in violation of any applicable federal, state, local or foreign law, statute, ordinance, rule, regulation, judgment, order, injunction, decree or agency requirement of or undertaking to or agreement with any Governmental Entity (collectively, “Laws” and each, a “Law”), except where such non-compliance, default or violation has not had and would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. (b) The Company and its Subsidiaries are in possession of all franchises, grants, authorizations, licenses, permits, easements, variances, exceptions, consents, certificates, approvals and orders of any Governmental Entity legally required for the Company and its Subsidiaries to own, lease and operate their properties and assets or to carry on their businesses as they are now being conducted (the “Company Permits”), except where the failure to have any of the Company Permits has not had and would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. All Company Permits are in full force and effect, except where the failure to be in full force and effect has not had and would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. No suspension or cancellation of any of the Company Permits is pending or, to the Company’s Knowledge, threatened, except where such suspension or cancellation has not had and would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. The Company and its Subsidiaries are not in violation or breach of, or default under, any Company Permit, except where such violation, breach or default has not had and would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect.

  • Consents, Permits, and Waivers The Company shall have obtained any and all consents, permits and waivers necessary or appropriate for consummation of the transactions contemplated by the Agreement and the Related Agreements.

  • Compliance with Laws; Licenses (a) The Company, each of the Retained Subsidiaries and the Retained Business since the Applicable Date has not been, and is not being, conducted in violation of any applicable federal, state, local, foreign or transnational law, statute or ordinance, common law, or any rule or regulation, including the Export and Sanctions Regulations (collectively, “Laws”) or any order, judgment, injunction, ruling, writ, award or decree of any Governmental Entity (collectively, “Order”), except for such violations that would not, individually or in the aggregate, reasonably be expected to have a Company Material Adverse Effect. To the Knowledge of the Company, no investigation or review by any Governmental Entity with respect to the Company, the Retained Subsidiaries or the Retained Business is pending or, as of the date of this Agreement, threatened, nor has any Governmental Entity indicated an intention to conduct the same, except for such investigations or reviews the outcome of which would not, individually or in the aggregate, reasonably be expected to have a Company Material Adverse Effect. Except as would not, individually or in the aggregate, reasonably be expected to have a Company Material Adverse Effect, after giving effect to the Separation, the Company and the Retained Subsidiaries possess each permit, license, certification, approval, registration, consent, authorization, franchise, concession, variance, exemption and order issued or granted by a Governmental Entity (collectively, “Licenses”) necessary to conduct the Retained Business as it is conducted as of the date of this Agreement. (b) Section 3.10(b) of the Company Disclosure Letter sets forth a complete and accurate list, as of the date of this Agreement, of (A) each License that is issued or granted by the FCC to the Company or any of its Subsidiaries that is material to the conduct of the Retained Business as it is conducted as of the date of this Agreement (each, a “RemainCo FCC License”), (B) each License that is issued or granted by a Foreign Regulator to the Company or any of its Subsidiaries that is material to the conduct of the Retained Business as it is conducted as of the date of this Agreement (each, a “RemainCo Foreign License”), and (C) all Licenses (other than the RemainCo FCC Licenses and the RemainCo Foreign Licenses) issued or granted to the Company or any of its Subsidiaries that is material to the conduct of the Retained Business as it is conducted as of the date of this Agreement by any Governmental Entity, authorizing the Company or any of its Subsidiaries to provide broadcasting and/or audio-visual media services, and/or own, operate or install broadcasting and/or audio-visual media networks and facilities, including satellites, or to use radio frequencies, excluding, in each case, any License that is material to the conduct of the Retained Business as conducted as of the date of this Agreement solely because of an existing television programming distribution arrangement between the Retained Business and the SpinCo Business (collectively with the RemainCo FCC Licenses and the RemainCo Foreign Licenses, the “RemainCo Communications Licenses”). Each of the Company and its Subsidiaries is in compliance with the RemainCo Communications Licenses and the rules and regulations of the Governmental Entities issuing such RemainCo Communications Licenses, except for failures to comply that are, individually and in the aggregate, not material to the Retained Business, taken as a whole. There is not pending or, to the Knowledge of the Company, threatened before the FCC or a Foreign Regulator or any other Governmental Entity, any material proceeding, notice of violation, order of forfeiture, inquiry, administrative action, complaint or investigation (A) against the Company or any of its Subsidiaries relating to the Retained Business, (B) relating to any of the RemainCo Communications Licenses, including any such proceeding, notice, order, inquiry, action, complaint or investigation reasonably likely to result in the revocation, suspension, cancellation, rescission or modification of any material RemainCo Communications License or other impairment in any material respect of the operation of the Retained Business as it is conducted as of the date of this Agreement, except (x) proceedings to amend the Communications Laws not directed at the Company or its Subsidiaries or (y) proceedings of general applicability to the broadcasting and/or audio-visual media services industries or (C) that would not, individually or in the aggregate, reasonably be expected to have a Company Material Adverse Effect. Except for restrictions or conditions that appear on the face of the RemainCo Communications Licenses, and except for restrictions or conditions that pertain to the RemainCo FCC Licenses under generally applicable rules of the FCC, to the Knowledge of the Company, no RemainCo Communications License held by the Company or any Subsidiary of the Company is subject to any restriction or condition which would limit the operation of the Retained Business as it is conducted as of the date of this Agreement, except for failures to comply that individually or in the aggregate would not be materially adverse to the Retained Business taken as a whole. (c) Except as would not be materially adverse to the Retained Business taken as a whole: (i) The Company, its Subsidiaries and, to the Knowledge of the Company, their respective officers, directors, employees and agents are in compliance in with and since the Applicable Date have complied with: (A) the provisions of the U.S. Foreign Corrupt Practices Act of 1977, as amended (15 U.S.C. § 78dd-1, et seq.) (“FCPA”) to the extent applicable to the Company, its Subsidiaries and such officers, directors, employees and agents, and (B) the provisions of applicable anti-bribery, anti-corruption and anti-money laundering Laws of each jurisdiction in which the Company and its Subsidiaries operate or have operated. Since the Applicable Date, to the Knowledge of the Company, the Company, its Subsidiaries and/or their respective officers, directors, employees and agents have not paid, offered or promised to pay, or authorized or ratified the payment, directly or indirectly, of any monies or anything of value to any national, provincial, municipal or other Government Official or any political party or candidate for political office for the purpose of corruptly influencing any act or decision of such official or of the government to obtain or retain business, or direct business to any person or to secure any other improper benefit or advantage, in each case in violation of any of the FCPA or any Laws described in clause (B). (ii) The Company and its Subsidiaries have instituted and maintain policies and procedures reasonably designed to ensure compliance with the FCPA and other anti-bribery, anti-corruption and anti-money laundering Laws in each jurisdiction in which the Company and its Subsidiaries operate. (iii) Neither the Company nor any of its Subsidiaries are subject to any actual, pending civil, criminal, or administrative actions, suits, demands, claims, hearings, notices of violation, investigations, proceedings, demand letters, settlements, or enforcement actions, or made any voluntary disclosures to any Governmental Entity, involving the Company or any of its Subsidiaries relating to the FCPA or any other anti-bribery, anti-corruption or anti-money laundering Laws

  • Compliance with Leases (i) Make all payments and otherwise perform all material obligations in respect of all leases of real property to which the Borrower or any of its Subsidiaries is a party, keep such leases in full force and effect and not allow such leases to lapse or be terminated or any rights to renew such leases to be forfeited or cancelled (except, in the case of the Borrower and Subsidiaries of the Borrower only, if in the reasonable business judgment of such Subsidiary it is in its best economic interest not to maintain such lease or prevent such lapse, termination, forfeiture or cancellation and such failure to maintain such lease or prevent such lapse, termination, forfeiture or cancellation is not in respect of a Qualifying Ground Lease or an Operating Lease of an Unencumbered Asset and could not otherwise reasonably be expected to result in a Material Adverse Effect), notify the Administrative Agent of any default by any party with respect to such leases and cooperate with the Administrative Agent in all respects to cure any such default, and cause each of its Subsidiaries to do so. (ii) With respect to any Qualifying Ground Lease related to any Unencumbered Asset: (A) pay when due the rent and other amounts due and payable thereunder (subject to applicable cure or grace periods); (B) timely perform and observe all of the material terms, covenants and conditions required to be performed and observed by it as tenant thereunder (subject to applicable cure or grace periods); (C) do all things necessary to preserve and keep unimpaired such Qualifying Ground Lease and its rights thereunder; (D) diligently and continuously enforce the material obligations of the lessor or other obligor thereunder; (E) deliver to the Administrative Agent all default and other material notices received by it or sent by it under the applicable Qualifying Ground Lease; (F) upon the Administrative Agent’s reasonable written request and at reasonable intervals, unless an Event of Default shall have occurred and be continuing, in which case, upon written request at any time, provide to the Administrative Agent any information or materials relating to such Qualifying Ground Lease and evidencing the applicable Subsidiary Guarantor’s due observance and performance of its material obligations thereunder; (G) in connection with the bankruptcy or other insolvency proceedings of any ground lessor or other obligor, ratify the legality, binding effect and enforceability of the applicable Qualifying Ground Lease within the applicable time period therefor in such proceedings, notwithstanding any rejection by such ground lessor or obligor or trustee, custodian or receiver related thereto; (H) at reasonable times and at reasonable intervals, deliver to the Administrative Agent (or, subject to the requirements of the subject Qualifying Ground Lease, cause the applicable lessor or other obligor to deliver to the Administrative Agent), an estoppel certificate and consent agreement in relation to such Qualifying Ground Lease in form and substance reasonably acceptable to the Administrative Agent, in its discretion, and, in the case of the estoppel certificate, setting forth (i) the name of lessee and lessor under the Qualifying Ground Lease (if applicable); (ii) that such Qualifying Ground Lease is in full force and effect and has not been modified except to the extent the Administrative Agent has received notice of such modification; (iii) that no rental and other payments due thereunder are delinquent as of the date of such estoppel; and (iv) whether such Person knows of any actual or alleged defaults or events of default under the applicable Qualifying Ground Lease; provided, that each Loan Party hereby agrees to execute and deliver to the Administrative Agent, within ten (10) days of any request therefor, such documents, instruments, agreements, assignments or other conveyances reasonably requested by the Administrative Agent in connection with or in furtherance of any of the provisions set forth above or the rights granted to the Administrative Agent in connection therewith.

  • Compliance with Laws; Permits Parent and each of its Subsidiaries are in compliance with and are not in default under or in violation of any applicable Law, except where such non-compliance, default or violation would not have and would not reasonably be expected to have, individually or in the aggregate, a Parent Material Adverse Effect. Since January 1, 2013, neither Parent nor any of its Subsidiaries has received any written notice from any Governmental Entity regarding any violation of, or failure to comply with, any Law, except as would not reasonably be expected to have, individually or in the aggregate, a Parent Material Adverse Effect. Parent and its Subsidiaries are in possession of all franchises, grants, authorizations, licenses, permits, easements, variances, exceptions, consents, certificates, approvals, clearances, permissions, qualifications and registrations and orders of all Governmental Entities, and all rights under any Parent Specified Contract with all Governmental Entities, and have filed all tariffs, reports, notices, and other documents with all Governmental Entities necessary for Parent and its Subsidiaries to own, lease and operate their properties and assets and to carry on their businesses as presently conducted (the “Parent Permits”), except where the failure to have any of the Parent Permits has not had and would not reasonably be expected to have, individually or in the aggregate, a Parent Material Adverse Effect. All Parent Permits are valid and in full force and effect and are not subject to any administrative or judicial proceeding that could result in modification, termination or revocation thereof, except where the failure to be in full force and effect or any modification, termination or revocation thereof has not had and would not reasonably be expected to have, individually or in the aggregate, a Parent Material Adverse Effect. Parent is, and each of its Subsidiaries is, in compliance with the terms and requirements of such Parent Permits, except where the failure to be in compliance has not had and would not reasonably be expected to have, individually or in the aggregate, a Parent Material Adverse Effect.

  • Possession of Licenses and Permits The Company and its subsidiaries possess such permits, licenses, approvals, consents and other authorizations (collectively, "Governmental Licenses") issued by the appropriate federal, state, local or foreign regulatory agencies or bodies necessary to conduct the business now operated by them; the Company and its subsidiaries are in compliance with the terms and conditions of all such Governmental Licenses, except where the failure so to comply would not, singly or in the aggregate, have a Material Adverse Effect; all of the Governmental Licenses are valid and in full force and effect, except when the invalidity of such Governmental Licenses or the failure of such Governmental Licenses to be in full force and effect would not have a Material Adverse Effect; and neither the Company nor any of its subsidiaries has received any notice of proceedings relating to the revocation or modification of any such Governmental Licenses which, singly or in the aggregate, if the subject of an unfavorable decision, ruling or finding, would result in a Material Adverse Effect.

  • Compliance with Laws and Contracts The Borrower and its Subsidiaries have complied in all material respects with all applicable statutes, rules, regulations, orders and restrictions of any domestic or foreign government or any instrumentality or agency thereof, having jurisdiction over the conduct of their respective businesses or the ownership of their respective properties, except where the failure to so comply could not reasonably be expected to have a Material Adverse Effect. Neither the execution and delivery by the Borrower of the Loan Documents, the application of the proceeds of the Loans, or any other transaction contemplated in the Loan Documents, nor compliance with the provisions of the Loan Documents will, or at the relevant time did, (a) violate any law, rule, regulation (including Regulation U), order, writ, judgment, injunction, decree or award binding on the Borrower or any Subsidiary or the Borrower's or any Subsidiary's charter, articles or certificate of incorporation or by-laws, (b) violate the provisions of or require the approval or consent of any party to any indenture, instrument or agreement to which the Borrower or any Subsidiary is a party or is subject, or by which it, or its property, is bound, or conflict with or constitute a default thereunder, or result in the creation or imposition of any Lien (other than Liens permitted by the Loan Documents) in, of or on the property of the Borrower or any Subsidiary pursuant to the terms of any such indenture, instrument or agreement, or (c) require any consent of the stockholders of any Person, except for any violation of, or failure to obtain an approval or consent required under, any such indenture, instrument or agreement that could not reasonably be expected to have a Material Adverse Effect.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!