Authorized Construction Representatives Sample Clauses

Authorized Construction Representatives. (a) Lessor’s Representative(s) set forth below shall be Lessor’s designated representative(s) for purposes of contact between Lessor and Lessee in connection with construction of the Lessor Improvements, including, without limitation, the giving of notices and approvals. Lessor shall have the right, upon two (2) days prior written notice given to Lessee in the manner provided in this Lease for the giving of notices, to remove any existing Lessor’s Representative(s) and to appoint other individual(s) to act as Lessor’s Representative(s). Lessor agrees that Lessor’s Representatives, or either of them, shall have the authority to bind Lessor with respect to all matters for which the consent or approval of Lessor is required or permitted in connection with the construction of the Lessor Improvements pursuant to this Exhibit A and that all consents, approvals and waivers given in writing by Lessor’s Representatives, or either of them, shall bind Lessor and may be relied upon by Lessee. Lessor’s Representative(s) is/are: […****…] (b) Lessee’s Representative(s) set forth below shall be Lessee’s designated representative(s) for purposes of contact between Lessee and Lessor in connection with construction of the Lessor Improvements, including, without limitation, the giving of notices and approvals. Lessee shall have the right, upon two (2) days prior written notice given to Lessor in the manner provided in this Lease for the giving of notices, to remove any existing Lessee’s Representative(s) and to appoint other employee(s) of Lessee to act as Lessee’s Representative(s). Lessee agrees that Lessee’s Representatives, or either of them, shall have the authority to bind Lessee with respect to all matters for which the consent or approval of Lessee is required or permitted in connection with the construction of the Lessor Improvements pursuant to this Exhibit A and that all consents, approvals and waivers given in writing by Lessee’s Representatives, or either of them, shall bind Lessee and may be relied upon by Lessor. Lessee’s Representative(s) is/are: (c) Where either party is required or permitted to submit plans, specifications, working drawing or similar materials under the provisions of this Exhibit A to the other party for review and/or consideration, the submitting party shall submit such documents and materials to the Lessor’s Representatives or the Lessee’s Representatives, as the case may be (which submittals may be delivered by electronic mail or posted u...
Sample 1
AutoNDA by SimpleDocs
Authorized Construction Representatives. Within five (5) days of Landlord's request, Tenant shall furnish Landlord with a written list of Tenant's authorized construction representatives for the Tenant Improvements. Only the authorized construction representatives on that list are authorized to (i) approve or change the Tenant Bid Documents, (ii) sign any change order, receipt or other document on behalf of Tenant related to the Tenant Improvements, or (iii) take any other action with respect to the construction of the Tenant Improvements permitted to be taken by Tenant hereunder. Tenant, from time to time, may change or add to the list of authorized construction representatives by giving Landlord written notice of the addition or change.
Sample 1

Related to Authorized Construction Representatives

  • Construction Representatives Landlord appoints the following person(s) as Landlord's representative ("Landlord's Representative") to act for Landlord in all matters covered by this Work Letter: ------------------------ ------------------------ ------------------------ Tenant appoints the following person(s) as Tenant's representative ("Tenant Representative") to act for Tenant in all matters covered by this Work Letter. ------------------------ ------------------------ ------------------------ All communications with respect to the matters covered by this Work Letter are to be made to Landlord's Representative or Tenant's Representative, as the case may be, in writing, in compliance with the notice provisions of the Lease. Either party may change its representative under this Work Letter at any time by written notice to the other party in compliance with the notice provisions of the Lease.

  • Union Representative Visits The Union shall inform the Employer in advance whenever the designated representatives of the Union intend to visit the Employer’s premises for the purpose of conducting Union business. Such visits shall not interfere with the normal operations of the worksite. Reasonable accommodation will be made to allow the Presidents of the Unions to have access to union members to conduct union business.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxx Xxxxxxxxx, Principal 00000 Xxxxxx Xxxxxxxx Xxxxxxx, Xxxxx 000, Xxxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: Xxx@XXXX.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx, Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • Union Representatives Upon mutual agreement of the parties, the number may be altered from time to time. Where a Union Representative commences on an extended leave of absence, the Union will endeavour to find a temporary replacement for the Union Representative from within the Home.

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • List of Union Representatives The Union agrees to provide and maintain an up-to-date list of all Union Representatives (including Union Stewards, Union Executive, Grievance Committee, Labour/Management Committee and Negotiating Committee) to the Director of Human Resources or designate.

  • Construction materials (1) The restrictions of section 1605 of the American Recovery and Reinvestment Act of 2009 (Pub. L. 111-5) (Recovery Act) do not apply to Recovery Act designated country manufactured construction material. The restrictions of the Buy American statute do not apply to designated country unmanufactured construction material. Consistent with U.S. obligations under international agreements, this clause implements--

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!