Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Parties; Limitation of Relationship This Agreement shall inure solely to the benefit of, and shall be binding upon, the Underwriters, the Company and the controlling Persons, directors, officers, employees and agents referred to in Sections 7 and 8 hereof, and their respective successors and assigns, and no other Person shall have or be construed to have any legal or equitable right, remedy or claim under or in respect of or by virtue of this Agreement or any provision herein contained. This Agreement and all conditions and provisions hereof are intended to be for the sole and exclusive benefit of the parties hereto and said controlling Persons and their respective successors, officers, directors, heirs and legal representative, and it is not for the benefit of any other Person. The term “successors and assigns” shall not include a purchaser, in its capacity as such, of Securities from any of the Underwriters.
Performance of Service; Limitation of Liability A. PFS shall exercise reasonable care in the performance of its duties under this Agreement. PFS shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with matters to which this Agreement relates, including losses resulting from mechanical breakdowns or the failure of communication or power supplies beyond PFS's control, except a loss arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence, or willful misconduct on its part in the performance of its duties under this Agreement. Notwithstanding any other provision of this Agreement, if PFS has exercised reasonable care in the performance of its duties under this Agreement, the Trust shall indemnify and hold harmless PFS from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which PFS may sustain or incur or which may be asserted against PFS by any person arising out of any action taken or omitted to be taken by it in performing the services hereunder, except for any and all claims, demands, losses, expenses, and liabilities arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence or from willful misconduct on its part in performance of its duties under this Agreement, (i) in accordance with the foregoing standards, or (ii) in reliance upon any written or oral instruction provided to PFS by any duly authorized officer of the Trust, such duly authorized officer to be included in a list of authorized officers furnished to PFS and as amended from time to time in writing by resolution of the Board of Trustees of the Trust. PFS shall indemnify and hold the Trust harmless from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which the Trust may sustain or incur or which may be asserted against the Trust by any person arising out of any action taken or omitted to be taken by PFS as a result of PFS's refusal or failure to comply with the terms of this Agreement, its bad faith, negligence, or willful misconduct. In the event of a mechanical breakdown or failure of communication or power supplies beyond its control, PFS shall take all reasonable steps to minimize service interruptions for any period that such interruption continues beyond PFS's control. PFS will make every reasonable effort to restore any lost or damaged data and correct any errors resulting from such a breakdown at the expense of PFS. PFS agrees that it shall, at all times, have reasonable contingency plans with appropriate parties, making reasonable provision for emergency use of electrical data processing equipment to the extent appropriate equipment is available. Representatives of the Trust shall be entitled to inspect PFS's premises and operating capabilities at any time during regular business hours of PFS, upon reasonable notice to PFS.
B. In order that the indemnification provisions contained in this section shall apply, it is understood that if in any case the indemnitor may be asked to indemnify or hold the indemnitee harmless, the indemnitor shall be fully and promptly advised of all pertinent facts concerning the situation in question, and it is further understood that the indemnitee will use all reasonable care to notify the indemnitor promptly concerning any situation which presents or appears likely to present the probability of a claim for indemnification. The indemnitor shall have the option to defend the indemnitee against any claim which may be the subject of this indemnification. In the event that the indemnitor so elects, it will so notify the indemnitee and thereupon the indemnitor shall take over complete defense of the claim, and the indemnitee shall in such situation initiate no further legal or other expenses for which it shall seek indemnification under this section. The indemnitee shall in no case confess any claim or make any compromise in any case in which the indemnitor will be asked to indemnify the indemnitee except with the indemnitor's prior written consent.
C. PFS is hereby expressly put on notice of the limitation of shareholder, Trustee, officer, employee or agent liability as set forth in the Declaration of Trust of the Trust and agrees that obligations assumed by the Trust pursuant to this Agreement shall be limited in all cases to the Trust and its assets, and if the liability relates to one or more Funds, the obligations hereunder shall be limited to the respective assets of such Fund. PFS further agrees that it shall not seek satisfaction of any such obligation from any shareholder of a Fund, nor from any Trustee, officer, employee or agent of the Trust.
Windstorm or hail This peril does not include loss to the property contained in a building caused by rain, snow, sleet, sand or dust unless the direct force of wind or hail damages the building causing an opening in a roof or wall and the rain, snow, sleet, sand or dust enters through this opening. This peril includes loss to watercraft and their trailers, furnishings, equipment, and outboard engines or motors, only while inside a fully enclosed building.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Tenant’s Remedies/Limitation of Liability Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.
NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
