Utilization Management Contractor shall maintain a utilization management program that complies with applicable laws, rules and regulations, including Health and Safety Code § 1367.01 and other requirements established by the applicable State Regulators responsible for oversight of Contractor.
Union Management Relations Any changes deemed necessary in this Agreement may be made by mutual agreement of the parties at any time during the life of this Agreement.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Files Management and Record Retention relating to Grantee and Administration of this Agreement a. The Grantee shall maintain books, records, and documents in accordance with generally accepted accounting procedures and practices which sufficiently and properly reflect all expenditures of funds provided by Florida Housing under this Agreement.
b. Contents of the Files: Grantee must maintain files containing documentation to verify all funds awarded to Grantee in connection with this Agreement, as well as reports, records, documents, papers, letters, computer files, or other material received, generated, maintained or filed by Grantee in connection with this Agreement. Grantee must also keep files, records, computer files, and reports that reflect any compensation it receives or will receive in connection with this Agreement.
Information Management Information and Records
Union/Management Committee There shall be a union/management committee comprised of four (4) employee representatives appointed by the Union and four (4) employer representatives. The Committee's purpose is to provide and promote effective and meaningful communication of information and ideas and to make joint recommendations on matters of concern. Matters that are properly the subject of an individual grievance will not be discussed at this committee. The Committee will meet quarterly, unless agreed otherwise, at a time and place mutually agreed to provided there is business for their joint consideration. The parties will exchange agenda items at least one (1) week prior to the meeting. The parties further agree the Committee may meet at any time its members mutually agree a meeting should be held. The duties of the Chairperson will be shared by the parties. Copies of the minutes shall be provided to Committee members. The employer agrees to pay for time spent during regular working hours for representatives of the union attending such meetings. The parties may utilize video or teleconferencing services for the purposes of committee members attending committee meetings, where appropriate and available. Neither party can unreasonably deny an initiative to utilize video or teleconferencing services.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
MANAGEMENT GRIEVANCES 14.01 It is understood that the Management may bring forward at any meeting held with the Union Representative any complaint with respect to the conduct of the Union, or Stewards, and that if such complaint by Management is not settled to the mutual satisfaction of the conferring Parties, it may be treated as a grievance and referred to arbitration in the same way as the grievance of any employee.
Joint Union/Management Committee It shall be appropriate for either the Union or the University to request that a Joint Union/Management committee be convened, with Environmental Health and Safety as a participating member, to discuss health and safety concerns and to explore options for addressing those concerns through appropriate training or other approaches.
