CHANGES TO PRODUCT OR SERVICE OFFERINGS a. Product or Service Discontinuance Where Contractor is the Product Manufacturer/Developer, and Contractor publicly announces to all U.S. customers (“date of notice”) that a Product is being withdrawn from the U.S. market or that maintenance service or technical support provided by Contractor (“withdrawn support”) is no longer going to be offered, Contractor shall be required to: (i) notify the Commissioner, each Licensee and each Authorized User then under contract for maintenance or technical support in writing of the intended discontinuance; and (ii) continue to offer Product or withdrawn support upon the Contract terms previously offered for the greater of: a) the best terms offered by Contractor to any other customer, or b) not less than twelve (12) months from the date of notice; and (iii) at Authorized User’s option, provided that the Authorized User is under contract for maintenance on the date of notice, either: provide the Authorized User with a Product replacement or migration path with at least equivalent functionality at no additional charge to enable Authorized User to continue use and maintenance of the Product. In the event that the Contractor is not the Product Manufacturer, Contractor shall be required to: (i) provide the notice required under the paragraph above, to the entities described within five (5) business days of Contractor receiving notice from the Product Manufacturer, and (ii) include in such notice the period of time from the date of notice that the Product Manufacturer will continue to provide Product or withdraw support. The provisions of this subdivision (a) shall not apply or eliminate Contractor’s obligations where withdrawn support is being provided by an independent Subcontractor. In the event that such Subcontractor ceases to provide service, Contractor shall be responsible for subcontracting such service, subject to state approval, to an alternate Subcontractor.
Changes to the Services We provide Services in a multi- user environment and must therefore reserve the right to modify and discontinue Services. We may modify a Service at any time without degrading its functionality or security features For current subscriptions, we may degrade the functionality of a Service or discontinue a Service only in case of (i) legal requirements; (ii) changes in the Services imposed by Siemens’ subcontractors; (iii) the termination of our relationship with a provider of software and/or services used by us which are material for the provision of such Service; (iv) lack of customer acceptance; and/or (v) security risks. We will notify you of any material degradation of functionality or the discontinuation of a Service and the effective date at least 80 days prior to such change, and you may terminate the modified Service 30 days prior to the change effective date. In the event of such termination or discontinuation of a Service, we will refund any prepaid amounts for the applicable Service on a pro-rata basis for the remaining Subscription Term. We do not maintain prior versions of a Service.
Changes to the Service We reserve the right to terminate, modify, add and remove features from the Service at any time in our sole discretion. You may reject changes by discontinuing use of the Service. Your continued use of the Service will constitute your acceptance of and agreement to such changes. Maintenance to the Service may be performed from time-to-time resulting in interrupted service, delays or errors in the Service and we shall have no liability for any such interruptions, delays or errors.
Changes to the Work 7.1 Changes to the Work may be accomplished by preparation of and execution of a change order or construction change directive. Change orders or construction change directives will be preceded by a change proposal request initiated by the Architect. The Construction Manager shall provide prices and details within 30 days of receipt of a change proposal request, and the Architect shall forward the completed change proposal request to the Owner within 15 days after receipt of the information provided by the Construction Manager.
Changes to Services The Parties acknowledge and agree that there will be changes to the scope of the Services during the Contract Period. The Customer may amend the Stories that are comprised within the Minimum Marketable Features of a Release at any time during the Release at no additional charge and without adopting the Change Control Procedure set out in Clause 28 above provided that: the Customer shall not be entitled to make any changes to the Stories that form the subject of a Sprint following the mutual agreement by the Parties of the Sprint Plan for that Sprint; new Stories and/or changes to existing Stories may only be introduced if: existing Stories with an equivalent number of Story Points are removed; or existing Stories are reduced in size by the equivalent number of Story Points, such that the total number of Story Points for the Release remains constant throughout the Release. The Supplier shall consider any request by the Customer to increase the number of Story Points for a Release, and may, subject to the Change Control Procedure set out at Clause 28, agree to such request.
Changes to the Website We may update the content on this Website from time to time, but its content is not necessarily complete or up-to-date. Any of the material on the Website may be out of date at any given time, and we are under no obligation to update such material.
No Warranty Regarding Goods or Services as Applicable We are not responsible for the quality, safety, legality, or any other aspect of any goods or services you purchase with the Card. Arbitration Any claim, dispute, or controversy (“Claim”) arising out of or relating in any way to: i) this Agreement; ii) the Card; iii) your acquisition of the Card; iv) your use of the Card; v) the amount of available funds in the Card Account; vi) advertisements, promotions or oral or written statements related to the Card, as well as goods or services purchased with the Card; vii) the benefits and services related to the Card; or viii) transactions on the Card, no matter how described, pleaded or styled, shall be FINALLY and EXCLUSIVELY resolved by binding individual arbitration conducted by the American Arbitration Association (“AAA”) under its Consumer Arbitration Rules. This arbitration agreement is made pursuant to a transaction involving interstate commerce, and shall be governed by the Federal Arbitration Act (9 U.S.C. 1-16). We will pay the initial filing fee to commence arbitration and any arbitration hearing that you attend shall take place in the federal judicial district of your residence. ARBITRATION OF YOUR CLAIM IS MANDATORY AND BINDING. NEITHER PARTY WILL HAVE THE RIGHT TO LITIGATE THAT CLAIM THROUGH A COURT. IN ARBITRATION, NEITHER PARTY WILL HAVE THE RIGHT TO A JURY TRIAL OR TO ENGAGE IN DISCOVERY, EXCEPT AS PROVIDED FOR IN THE AAA CODE OF PROCEDURE. For a copy of the procedures, to file a Claim or for other information about this organization, contact it at: AAA, 000 Xxxxxxx Xxxxxx, Xxx Xxxx, XX 00000, or at xxx.xxx.xxx. All determinations as to the scope, interpretation, enforceability and validity of this Agreement shall be made final exclusively by the arbitrator, which award shall be binding and final. Judgment on the arbitration award may be entered in any court having jurisdiction. NO CLASS ACTION, OR OTHER REPRESENTATIVE ACTION OR PRIVATE ATTORNEY GENERAL ACTION OR JOINDER OR CONSOLIDATION OF ANY CLAIM WITH A CLAIM OF ANOTHER PERSON OR CLASS OF CLAIMANTS SHALL BE ALLOWABLE. This arbitration provision shall survive: i) the termination of the Agreement; ii) the bankruptcy of any party; iii) any transfer, sale or assignment of the Card, or any amounts owed on the Card, to any other person or entity; or iv) expiration of the Card. If any portion of this arbitration provision is deemed invalid or unenforceable, the remaining portions shall remain in force. IF YOU DO NOT AGREE TO THE TERMS OF THIS ARBITRATION AGREEMENT, DO NOT ACTIVATE OR USE THE CARD. CALL 0-000-000-0000 TO CANCEL THE CARD AND MAKE ALTERNATE ARRANGEMENTS TO RECEIVE THE FUNDS ASSOCIATED WITH THE CARD ACCOUNT.
Changes to the Project 9.1 All Changes must be approved by the Secretary of State prior to the relevant Change being deemed to be effective. The Grant Recipient shall request the Change on a Project Change Request Form. The Secretary of State shall either agree to the change request or reject the change request within 60 days of the date of the Project Change Request Form.
Changes to Service We may, from time to time, modify the Service to reflect improvements and other changes and modifications to our network. In addition, we reserve the right to discontinue or limit Service as required to comply with or satisfy our obligations under applicable laws or regulations, including when changes to or interpretations of such laws and regulations have a material, adverse effect on the business, technical or economic feasibility of providing Service, as determined by us in our reasonable judgment.
Changes to the Terms of Use We may revise and update these Terms of Use from time to time in our sole discretion. All changes are effective immediately when we post them, and apply to all access to and use of the Website thereafter. Your continued use of the Website following the posting of revised Terms of Use means that you accept and agree to the changes. You are expected to check this page from time to time so you are aware of any changes, as they are binding on you.
