Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Termination as a Result of Death or Disability The Executive’s employment with the Company shall terminate automatically upon the Executive’s death during the Employment Term. If the Disability of the Executive has occurred during the Employment Term (pursuant to the definition of “Disability” set forth below), the Company may give to the Executive written notice of its intention to terminate the Executive’s employment. In such event, the Executive’s employment with the Company shall terminate effective on the 30th day after receipt of such notice by the Company (the “Disability Effective Date”), provided that, within the 30 days after receipt of notice, the Executive shall not have returned to substantial performance of the Executive’s duties. For purposes of this Agreement, “Disability” shall mean the absence of the Executive from the Executive’s duties with the Company for 120 consecutive days, or a total of 180 days in any 12-month period, as a result of incapacity due to mental or physical illness which is determined to be total and permanent by a physician jointly selected by the Company and the Executive or the Executive’s legal representative, or, if the parties cannot agree on the selection of such physician then each shall choose a physician and the two physicians shall jointly select a physician to make such binding determination.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
EFFECTIVENESS; TERMINATION This Delegation Schedule shall be effective as of the date on which this Delegation Schedule shall have been accepted by the Delegate, as indicated by the date set forth below the Delegate's signature. This Delegation Schedule may be terminated at any time, without penalty, by written notice from the terminating party to the non-terminating party. Such termination shall be effective on the 30th calendar day following the date on which the non-terminating party shall receive the foregoing notice. The foregoing to the contrary notwithstanding, this Delegation Schedule shall be deemed to have been terminated concurrently with the termination of the Custodian Agreement.
Death or Disability The Executive's employment shall terminate automatically upon the Executive's death during the Employment Period. If the Company determines in good faith that the Disability of the Executive has occurred during the Employment Period (pursuant to the definition of Disability set forth below), it may give to the Executive written notice in accordance with Section 12(b) of this Agreement of its intention to terminate the Executive's employment. In such event, the Executive's employment with the Company shall terminate effective on the 30th day after receipt of such notice by the Executive (the "Disability Effective Date"), provided that, within the 30 days after such receipt, the Executive shall not have returned to full-time performance of the Executive's duties. For purposes of this Agreement, "Disability" shall mean the absence of the Executive from the Executive's duties with the Company on a full-time basis for 180 consecutive business days as a result of incapacity due to mental or physical illness which is determined to be total and permanent by a physician selected by the Company or its insurers and acceptable to the Executive or the Executive's legal representative.
Termination Due to Death or Disability The expiration of one (1) year from the date of the death of the Optionee or cessation of an Optionee’s employment or contractual relationship by reason of disability (as defined in Section 5.1(g) of the Plan). If an Optionee’s employment or contractual relationship is terminated by death, any Option held by the Optionee shall be exercisable only by the person or persons to whom such Optionee’s rights under such Option shall pass by the Optionee’s will or by the laws of descent and distribution.
