Claim Format Sample Clauses

Claim Format. All Claims must be in writing and sent to County by registered or certified mail, return receipt requested. The Claim submitted by Contractor shall include, but not be limited to, the following: (a) A cover letter and certification under penalty of perjury of the accuracy of the contents of the Claim; (b) A summary of the Claim including underlying facts, entitlement, schedule analysis, quantum calculations and Contract provisions supporting relief; (c) A list of documents relating to the Claim including Specifications, Drawings, Requests for Clarification/RFIs, schedules, notices of delay, cost calculations and spreadsheets, and any other relevant documents: (d) A chronology of events and correspondence; (e) An analysis of Claim merit; (f) An analysis of Claim cost; and (g) All supporting documents referenced in (c).
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Claim Format. Any claim for an equitable adjustment of the Contract Price and/or the Contract Time of performance, including but not limited to changes ordered by either the Owner or Contractor must be made in writing with detailed breakdown as required by the Contract Documents. Pricing must be prepared according to the labor rates and equipment rates established in the PROJECT SUBCONTRACT AGREEMENT.
Sample 1
Claim Format. All Claims must be in writing and sent to County by registered or certified mail, return receipt requested. The Claim submitted by Developer shall include, but not be limited to, the following: (a) a cover letter and certification under penalty of perjury of the accuracy of the contents of the Claim; (b) a summary of the Claim including underlying facts, entitlement, schedule analysis, quantum calculations and Agreement provisions supporting relief;
Sample 1
Claim Format. A. Contractor shall submit the formal claim(s) with a cover letter and certification of the accuracy of the formal claim. B. The formal claim(s) shall list separately each notice of potential claim that Contractor intends to pursue as a formal claim(s), and for each such item separately, Contractor shall provide the following: 1. Summary of the claim, including underlying facts, entitlement, schedule analysis, quantum calculations, contract provisions supporting relief; 2. List of documents relating to claim including Specifications, Drawings, clarifications/requests for information, schedules, notices of delay, and any others; 3. Chronology of events and correspondence; 4. Analysis of claim merit; 5. Analysis of claim cost; and 6. Attach supporting cost and schedule documents as required in this Article and elsewhere in the Contract Documents (e.g., Section 01 3230 [Progress Schedules and Reports]). C. For each notice of potential claim that Contractor intends to pursue as a formal claim, Contractor shall establish in the formal claim a direct causal link between the separate item of cost/time requested, the separate notices of potential claim timely issued, and the specific changed Work asserted. Total cost claims shall not be allowed. D. Claims shall be calculated in the same manner as Change Orders per Section 01 2600 (Modification Procedures).
Sample 1
Claim Format. The Contractor shall submit the Claim justification in the following format: (1) Cover letter and certification of the accuracy of the contents of the Claim; (2) Summary of Claim including underlying facts, entitlement, quantum calculations, and Contract Document provision supporting relief; (3) List of documents relating to the Claim, including plans, specifications, clarifications/requests for information, schedules and others; (4) Chronology of events and correspondence; (5) Analysis of Claim merit; (6) Analysis of Claim costs; (7) Attached supporting documents referenced in item (3) above.
Sample 1

Related to Claim Format

  • Sending a Claim Notice Before beginning a lawsuit, mediation or arbitration, you and we agree to send a written notice (a claim notice) to each party against whom a claim is asserted, in order to provide an opportunity to resolve the claim informally or through mediation. Go to xxxxxxxxxxxxxxx.xxx/ claim for a sample claim notice. The claim notice must describe the claim and state the specific relief demanded. Notice to you may be provided by your billing statement or sent to your billing address. Notice to us must include your name, address and Account number and be sent to American Express ADR c/o CT Corporation System, 00 Xxxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000. If the claim proceeds to arbitration, the amount of any relief demanded in a claim notice will not be disclosed to the arbitrator until after the arbitrator rules.

  • Claims Submission Unless otherwise prohibited by federal or state law, Provider will submit Clean Claims for all Covered Services to BCBSM within one hundred eighty (180) days of the date of service.

  • Claim Notice A Party that seeks indemnity under this Article X (an “Indemnified Party”) will give written notice (a “Claim Notice”) to the Party from whom indemnification is sought (an “Indemnifying Party”), whether the Damages sought arise from matters solely between the Parties or from Third Party Claims. The Claim Notice must contain (i) a description and, if known, estimated amount (the “Claimed Amount”) of any Damages incurred or reasonably expected to be incurred by the Indemnified Party, (ii) a reasonable explanation of the basis for the Claim Notice to the extent of facts then known by the Indemnified Party, and (iii) a demand for payment of those Damages. No delay or deficiency on the part of the Indemnified Party in so notifying the Indemnifying Party will relieve the Indemnifying Party of any liability for Damages or obligation hereunder except to the extent of any Damages caused by or arising out of such failure.

  • Product Claims The parties acknowledge that NCR Voyix, not Apple, is responsible for addressing any claims you or any third party relating to the Software or your possession and/or use of the Software, including, but not limited to: (a) product liability claims; (b) any claim that the Software fails to conform to any applicable legal or regulatory requirement; and (c) claims arising under consumer protection or similar legislation.

  • Claim of Infringement In the event that use of any facilities or equipment (including software), becomes, or in the reasonable judgment of the Party who owns the affected network is likely to become, the subject of a claim, action, suit, or proceeding based on intellectual property infringement, then said Party shall promptly and at its sole expense and sole option, but subject to the limitations of liability set forth below: 9.4.1 modify or replace the applicable facilities or equipment (including software) while maintaining form and function, or 9.4.2 obtain a license sufficient to allow such use to continue. 9.4.3 In the event 9.4.1 or 9.4.2 are commercially unreasonable, then said Party may, terminate, upon reasonable notice, this contract with respect to use of, or services provided through use of, the affected facilities or equipment (including software), but solely to the extent required to avoid the infringement claim.

  • Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

  • Notice of Loss; Third Party Claims (a) An Indemnified Party shall give the Indemnifying Party notice of any matter that an Indemnified Party has determined has given or could give rise to a right of indemnification under this Agreement, within thirty (30) days of such determination, stating the amount of the Loss, if known, and method of computation thereof, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises. (b) If an Indemnified Party shall receive notice of any Action, audit, demand or assessment (each, a “Third Party Claim”) against it or which may give rise to a claim for a Loss under this Article VIII, within thirty (30) days of the receipt of such notice, the Indemnified Party shall give the Indemnifying Party notice of such Third Party Claim; provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VIII except to the extent that the Indemnifying Party is materially prejudiced by such failure and shall not relieve the Indemnifying Party from any other obligation or liability that it may have to any Indemnified Party otherwise than under this Article VIII. If the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party hereunder against any Losses that may result from such Third Party Claim, then the Indemnifying Party shall be entitled to assume and control the defense of such Third Party Claim at its expense and through counsel of its choice if it gives notice of its intention to do so to the Indemnified Party within five (5) days of the receipt of notice from the Indemnified Party of such Third Party Claim; provided, however, that if there exists or is reasonably likely to exist a conflict of interest that would make it inappropriate in the judgment of the Indemnified Party in its sole and absolute discretion for the same counsel to represent both the Indemnified Party and the Indemnifying Party, then the Indemnified Party shall be entitled to retain its own counsel in each jurisdiction for which the Indemnified Party determines counsel is required, at the expense of the Indemnifying Party. In the event that the Indemnifying Party exercises the right to undertake any such defense against any such Third Party Claim as provided above, the Indemnified Party shall cooperate with the Indemnifying Party in such defense and make available to the Indemnifying Party, at the Indemnifying Party’s expense, all witnesses, pertinent records, materials and information in the Indemnified Party’s possession or under the Indemnified Party’s control relating thereto as is reasonably required by the Indemnifying Party. Similarly, in the event the Indemnified Party is, directly or indirectly, conducting the defense against any such Third Party Claim, the Indemnifying Party shall cooperate with the Indemnified Party in such defense and make available to the Indemnified Party, at the Indemnifying Party’s expense, all such witnesses, records, materials and information in the Indemnifying Party’s possession or under the Indemnifying Party’s control relating thereto as is reasonably required by the Indemnified Party. No such Third Party Claim may be settled by the Indemnifying Party without the prior written consent of the Indemnified Party.

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • CLAIM EXPENSES The Reinsurer will pay its share of reasonable claim investigation and legal expenses connected with the litigation or settlement of contractual liability claims unless the Reinsurer has discharged its liability pursuant to Section 9.4 above. If the Reinsurer has so discharged its liability, the Reinsurer will not participate in any expenses incurred thereafter. The Reinsurer will not reimburse the Ceding Company for routine claim and administration expenses, including but not limited to the Ceding Company's home office expenses, compensation of salaried officers and employees, and any legal expenses other than third party expenses incurred by the Ceding Company. Claim investigation expenses do not include expenses incurred by the Ceding Company as a result of a dispute or contest arising out of conflicting claims of entitlement to policy proceeds or benefits.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!