CLAIMS AND DISPUTES SUBJECT TO ARBITRATION Sample Clauses

CLAIMS AND DISPUTES SUBJECT TO ARBITRATION. 8.8.1. Disputes or claims arising out of or related to this Contract or the breach thereof, which do not exceed the monetary limits hereinafter set forth, shall be settled by arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association. Judgment upon the award rendered by the Arbitrator or Arbitrators may be entered in any court of the State of New York having jurisdiction thereof, except disputes or claims relating to aesthetic effect and except those waived by the Design- Builder expressly or by failure of the Design- Builder to preserve such claims as required by these General Conditions, and provided further that the notice of arbitration is strictly made and served within the time limits set forth herein and within the monetary limits set forth herein. 8.8.2. Demand for arbitration of any claim arbitrable, as provided herein, may not be made and served until the Certificate of Substantial Completion has been issued. Such claims must be made and served no later than six (6) months after receipt by the Owner of the Design-Builder's Application for Final Payment or, if the Contract is terminated by the Owner, no later than six (6) months after the date of said termination. Any demand for arbitration of any claim made before issuance of the Certificate of Substantial Completion shall be deemed null and void and further shall constitute a waiver of any such claims. 8.8.3. No Claim alleged in excess of $10,000.00 shall be subject to Arbitration provided however, if Design-Builder has preserved multiple claims, all of which are less than $10,000.00 and in the aggregate all preserved claims are less than $50,000.00, then all such claims shall be arbitrated. Provided, further if any claim preserved by the Design- Builder and not waived by Design-Builder exceeds $10,000.00 or claims preserved and not waived by the Design-Builder in the aggregate exceed $50,000.00 then Design-Builder shall not be entitled to arbitration for any claim. 8.8.4. As a condition precedent and prior to making demand for arbitration as provided for herein. the Design- Builder shall deliver to the Owner a duly executed and acknowledged waiver and release waiving, and releasing the Owner from, any and all claims to the extent said claims exceed the sum of $50,000.00. Such waiver and release shall be in addition to, and cumulative with, any other waivers and releases required by the Contract Documents or given by the Design- Builder; it...
Sample 1
AutoNDA by SimpleDocs

Related to CLAIMS AND DISPUTES SUBJECT TO ARBITRATION

  • Disputes Subject to Arbitration Any claim, dispute or controversy arising out of this Agreement (other than claims relating to misuse or misappropriation of the intellectual property of the Company), the interpretation, validity or enforceability of this Agreement or the alleged breach thereof shall be submitted by the parties to binding arbitration by a sole arbitrator under the rules of the American Arbitration Association; provided, however, that (a) the arbitrator shall have no authority to make any ruling or judgment that would confer any rights with respect to the trade secrets, confidential and proprietary information or other intellectual property of the Company upon the Executive or any third party; and (b) this arbitration provision shall not preclude the Company from seeking legal and equitable relief from any court having jurisdiction with respect to any disputes or claims relating to or arising out of the misuse or misappropriation of the Company’s intellectual property. Judgment may be entered on the award of the arbitrator in any court having jurisdiction.

  • Claims Subject to Arbitration Except as expressly provided below, the parties agree that to the fullest extent permitted by applicable law, any dispute arising out of or relating in any way to this Agreement or a similar prior agreement, the Property or the relationship between Resident and Owner or Manager (including matters occurring prior to the date of this Agreement and disputes also involving third parties) (collectively, “Claims”) will, at the election of either party, be resolved by arbitration, including any dispute about arbitrability, such as scope and enforceability.

  • Claims Not Subject to Arbitration 13.6.3.1 If the following claims are not resolved through informal Dispute Resolution, they will not be subject to arbitration and must be resolved through any remedy available to a Party pursuant to law, equity or agency mechanism: 13.6.3.1.1 Actions seeking a temporary restraining order or an injunction related to the purposes of this Agreement. 13.6.3.1.2 All claims arising under federal or state statute(s), including antitrust claims.

  • Claims Subject to Mandatory Arbitration The following claims, if not settled through informal Dispute Resolution, will be subject to mandatory arbitration pursuant to Section 10.7 below: 10.6.2.1 Each unresolved billing dispute involving one percent (1%) or less of the amounts charged to the Disputing Party under this Agreement in the state in which the dispute arises during the twelve (12) months immediately preceding receipt of the letter initiating Dispute Resolution under Section 10.3. If the disputing Party has not been billed for a minimum of twelve (12) months immediately preceding receipt of the letter initiating Dispute Resolution under Section 10.3, the Parties will annualize the actual number of months billed.

  • Settlement of Disputes; Arbitration All claims by the Executive for benefits under this Agreement shall be directed to and determined by the Board of Directors of the Company and shall be in writing. Any denial by the Board of Directors of a claim for benefits under this Agreement shall be delivered to the Executive in writing and shall set forth the specific reasons for the denial and the specific provisions of this Agreement relied upon. The Board of Directors shall afford a reasonable opportunity to the Executive for a review of the decision denying a claim. Any further dispute or controversy arising under or in connection with this Agreement shall be settled exclusively by arbitration in Boston, Massachusetts, in accordance with the rules of the American Arbitration Association then in effect. Judgment may be entered on the arbitrator's award in any court having jurisdiction.

  • GOVERNING LAW; DISPUTES SUBMITTED TO ARBITRATION All disputes arising under this agreement shall be governed by and interpreted in accordance with the laws of the Commonwealth of Massachusetts, without regard to principles of conflict of laws. The parties to this agreement will submit all disputes arising under this agreement to arbitration in Boston, Massachusetts before a single arbitrator of the American Arbitration Association (“AAA”). The arbitrator shall be selected by application of the rules of the AAA, or by mutual agreement of the parties, except that such arbitrator shall be an attorney admitted to practice law in the Commonwealth of Massachusetts. No party to this agreement will challenge the jurisdiction or venue provisions as provided in this section. No party to this agreement will challenge the jurisdiction or venue provisions as provided in this section. Nothing contained herein shall prevent the party from obtaining an injunction.

  • Claims Subject to Elective Arbitration 13.6.2.1 Claims will be subject to elective arbitration pursuant to Section 13.7 below, if, and only if, the claim is not settled through informal Dispute Resolution and both Parties agree to arbitration. If both Parties do not agree to arbitration, then either Party may proceed with any remedy available to it pursuant to law, equity or agency mechanism.

  • Disputes/Arbitration (a) If a dispute arises between the parties, the parties agree that their respective representatives shall meet and consult in good faith and attempt to settle the dispute, within thirty (30) days of written notice thereof, as a condition precedent to the initiation of arbitration proceedings as set forth herein. Notwithstanding any other provision of this Agreement to the contrary, the parties hereto agree that any and all disputes with respect to any claim pursuant to the provisions of this Agreement, shall be settled by arbitration in accordance with the Commercial Arbitration Rules of the American Arbitration Association by a panel of three (3) arbitrators appointed pursuant to such Rules, and judgment upon the award rendered by such arbitrators may be entered in any court having jurisdiction. Such arbitrators shall not have the authority or power to reform, alter, amend or modify any of the terms or conditions of this Agreement or to enter an award which reforms, alters, amends or modifies such terms or conditions. Notwithstanding the forgoing, the arbitrators shall have no authority to award any punitive damages except upon proof of fraud with intent to deceive. The decision of such arbitrators shall be in writing, setting forth both findings of fact and conclusions of law, and shall be final and conclusive upon the parties; and no suit at law or in equity based on such dispute, controversy or claim shall be instituted by any party hereto, other than to enforce the award of such arbitrators. Such arbitration shall be conducted in Denver, Colorado or in such other location as the parties thereto may agree. (b) In the event of a dispute, the prevailing party shall be entitled to be reimbursed by the non-prevailing party or parties for such prevailing party's reasonable attorney's fees and other expenses. (c) The parties agree that as precondition to the commencement of arbitration by any party, the dispute must be submitted to non-binding mediation with a mediator agreed to by both parties. If the parties cannot agree on a mediator within fourteen (14) days from the date of a request for mediation, the dispute will be mediated by a person selected in accordance with the rules of the American Arbitration Association.

  • Mediation and Arbitration of Disputes An Addendum requiring the Mediation and/or the Arbitration of all disputes between the Parties and/or Brokers arising out of this Lease ¨ is x is not attached to this Lease. LESSOR AND LESSEE HAVE CAREFULLY READ AND REVIEWED THIS LEASE AND EACH TERM AND PROVISION CONTAINED HEREIN, AND BY THE EXECUTION OF THIS LEASE SHOW THEIR INFORMED AND VOLUNTARY CONSENT THERETO. THE PARTIES HEREBY AGREE THAT, AT THE TIME THIS LEASE IS EXECUTED, THE TERMS OF THIS LEASE ARE COMMERCIALLY REASONABLE AND EFFECTUATE THE INTENT AND PURPOSE OF LESSOR AND LESSEE WITH RESPECT TO THE PREMISES. ATTENTION: NO REPRESENTATION OR RECOMMENDATION IS MADE BY THE AMERICAN INDUSTRIAL REAL ESTATE ASSOCIATION OR BY ANY BROKER AS TO THE LEGAL SUFFICIENCY, LEGAL EFFECT, OR TAX CONSEQUENCES OF THIS LEASE OR THE TRANSACTION TO WHICH IT RELATES. THE PARTIES ARE URGED TO: 1. SEEK ADVICE OF COUNSEL AS TO THE LEGAL AND TAX CONSEQUENCES OF THIS LEASE. 2. RETAIN APPROPRIATE CONSULTANTS TO REVIEW AND INVESTIGATE THE CONDITION OF THE PREMISES. SAID INVESTIGATION SHOULD INCLUDE BUT NOT BE LIMITED TO: THE POSSIBLE PRESENCE OF HAZARDOUS SUBSTANCES, THE ZONING OF THE PREMISES, THE STRUCTURAL INTEGRITY, THE CONDITION OF THE ROOF AND OPERATING SYSTEMS, AND THE SUITABILITY OF THE PREMISES FOR LESSEE’S INTENDED USE.

  • Disputes and Arbitration Any dispute concerning a question of fact arising under this contract shall be disposed of by good faith negotiation between duly authorized representatives of the District, the Office of the State Auditor, and the Firm. Such a resolution shall be reduced to writing and a copy thereof mailed or furnished to the Firm and shall be final and conclusive.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!